LIQUIDATED DAMAGE CAP Sample Clauses

Open Split View

Download

Share

Cite

LIQUIDATED DAMAGE CAP. If imposed, Liquidated Damages will not exceed (ten percent (10%)) of the base Agreement Amount.

Sample 1Sample 2

Save

Copy

Related to LIQUIDATED DAMAGE CAP

• Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

• Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.

• Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.

• Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.

• CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is April 25, 2016. The completion date for this contract is October 15, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.

• Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.

• Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Xxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.

• Severability; Maximum Payment Amounts If any provision of this Agreement is prohibited by law or otherwise determined to be invalid or unenforceable by a court of competent jurisdiction, the provision that would otherwise be prohibited, invalid or unenforceable shall be deemed amended to apply to the broadest extent that it would be valid and enforceable, and the invalidity or unenforceability of such provision shall not affect the validity of the remaining provisions of this Agreement so long as this Agreement as so modified continues to express, without material change, the original intentions of the parties as to the subject matter hereof and the prohibited nature, invalidity or unenforceability of the provision(s) in question does not substantially impair the respective expectations or reciprocal obligations of the parties or the practical realization of the benefits that would otherwise be conferred upon the parties. The parties will endeavor in good faith negotiations to replace the prohibited, invalid or unenforceable provision(s) with a valid provision(s), the effect of which comes as close as possible to that of the prohibited, invalid or unenforceable provision(s). Notwithstanding anything to the contrary contained in this Agreement or any other Transaction Document (and without implication that the following is required or applicable), it is the intention of the parties that in no event shall amounts and value paid by the Company and/or any of its Subsidiaries (as the case may be), or payable to or received by any of the Buyers, under the Transaction Documents (including without limitation, any amounts that would be characterized as “interest” under applicable law) exceed amounts permitted under any applicable law. Accordingly, if any obligation to pay, payment made to any Buyer, or collection by any Buyer pursuant the Transaction Documents is finally judicially determined to be contrary to any such applicable law, such obligation to pay, payment or collection shall be deemed to have been made by mutual mistake of such Buyer, the Company and its Subsidiaries and such amount shall be deemed to have been adjusted with retroactive effect to the maximum amount or rate of interest, as the case may be, as would not be so prohibited by the applicable law. Such adjustment shall be effected, to the extent necessary, by reducing or refunding, at the option of such Buyer, the amount of interest or any other amounts which would constitute unlawful amounts required to be paid or actually paid to such Buyer under the Transaction Documents. For greater certainty, to the extent that any interest, charges, fees, expenses or other amounts required to be paid to or received by such Buyer under any of the Transaction Documents or related thereto are held to be within the meaning of “interest” or another applicable term to otherwise be violative of applicable law, such amounts shall be pro-rated over the period of time to which they relate.

• Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS. B. Such liquidated damages shall be calculated as an amount equaling the difference between: 1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and 2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract. C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.

• Shift Premium Full-Time and Part-Time Employees shall be paid a shift premium of one dollar ($1.00) per hour for all hours worked where the majority of their scheduled hours fall between 1500 and 0700 hours.