Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all tax benefits and other reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.
Maximum Liability The provisions of this Loan Guaranty are severable, and in any action or proceeding involving any state corporate law, or any state, federal or foreign bankruptcy, insolvency, reorganization or other law affecting the rights of creditors generally, if the obligations of any Loan Guarantor under this Loan Guaranty would otherwise be held or determined to be avoidable, invalid or unenforceable on account of the amount of such Loan Guarantor’s liability under this Loan Guaranty, then, notwithstanding any other provision of this Loan Guaranty to the contrary, the amount of such liability shall, without any further action by the Loan Guarantors or the Lenders, be automatically limited and reduced to the highest amount that is valid and enforceable as determined in such action or proceeding (such highest amount determined hereunder being the relevant Loan Guarantor’s “Maximum Liability”. This Section with respect to the Maximum Liability of each Loan Guarantor is intended solely to preserve the rights of the Lenders to the maximum extent not subject to avoidance under applicable law, and no Loan Guarantor nor any other person or entity shall have any right or claim under this Section with respect to such Maximum Liability, except to the extent necessary so that the obligations of any Loan Guarantor hereunder shall not be rendered voidable under applicable law. Each Loan Guarantor agrees that the Guaranteed Obligations may at any time and from time to time exceed the Maximum Liability of each Loan Guarantor without impairing this Loan Guaranty or affecting the rights and remedies of the Lenders hereunder, provided that, nothing in this sentence shall be construed to increase any Loan Guarantor’s obligations hereunder beyond its Maximum Liability.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Termination Damages If the Term of this Lease is terminated for default, unless and until Landlord elects lump sum liquidated damages described in the next paragraph, Tenant covenants, as an additional, cumulative obligation after any such termination, to pay punctually to Landlord all the sums and perform all of its obligations in the same manner as if the Term had not been terminated. In calculating such amounts Tenant will be credited with the net proceeds of any rent then actually received by Landlord from a reletting of the Premises after deducting all Rent that has not then been paid by Tenant, provided that Tenant shall never be entitled to receive any portion of the re-letting proceeds, even if the same exceed the Rent originally due hereunder.
Aggregate Amount The aggregate principal amount of the Notes that may be initially authenticated and delivered under the Third Supplemental Indenture shall be U.S.$750,000,000. As provided in the Original Indenture, the Company may, from time to time, without the consent of the Holders of Notes, issue Add On Notes having identical terms (including CUSIP, ISSN and other relevant identifying characteristics as the Notes), so long as, on the date of issuance of such Add On Notes: (i) no Default or Event of Default shall have occurred and then be continuing, or shall occur as a result of the issuance of such Add On Notes, (ii) such Add On Notes shall rank pari passu with the Notes and shall have identical terms, conditions and benefits as the Notes and be part of the same series as the Notes, (iii) the Company and the Trustee shall have executed and delivered a further supplemental indenture to the Indenture providing for the issuance of such Add On Notes and reflecting such amendments to the Indenture as may be required to reflect the increase in the aggregate principal amount of the Notes resulting from the issuance of the Add On Notes, (iv) Petrobras and the Trustee shall have executed and delivered an amended Standby Purchase Agreement reflecting the increase in the aggregate principal amount of the Notes resulting from the issuance of the Add On Notes and (v) the Trustee shall have received all such opinions and other documents as it shall have requested, including an Opinion of Counsel stating that such Add On Notes are authorized and permitted by the Indenture and all conditions precedent to the issuance of such Add On Notes have been complied with by the Company and Petrobras. All Add On Notes issued hereunder will, when issued, be considered Notes for all purposes hereunder and will be subject to and take the benefit of all of the terms, conditions and provisions of this Indenture.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Payment of Amounts Due (a) In case an Event of Default described in clause (a) of Section 2.01 shall have happened and be continuing, then, upon demand of Beneficiary, Grantor will pay to Beneficiary the whole amount which then shall have become due and payable on the Note, for principal or interest or both, as the case may be, and after the happening of said Event of Default will also pay to Beneficiary interest at the Default Rate on the then unpaid principal of the Note, and the sums required to be paid by Grantor pursuant to any provision hereof, and in addition thereto such further amount as shall be sufficient to cover the costs and expenses of collection, including reasonable compensation to Trustee and Beneficiary, their agents and counsel and any expenses incurred by Trustee or Beneficiary hereunder. In the event Grantor shall fail forthwith to pay all such amounts upon such demand, Beneficiary shall be entitled and empowered to institute such action or proceedings at law or in equity as may be advised by its counsel for the collection of the sums so due and unpaid, and may prosecute any such action or proceedings to judgment or final decree, and may enforce any such judgment or final decree against Grantor and collect, out of the property of Grantor wherever situated, as well as out of the Mortgaged Property, in any manner provided by law, moneys adjudged or decreed to be payable.
Direct Damages A PARTY’S DAMAGES RESULTING FROM A BREACH OR VIOLATION OF ANY REPRESENTATION, WARRANTY, COVENANT, AGREEMENT OR CONDITION CONTAINED IN THIS AGREEMENT OR ANY ACT OR OMISSION ARISING FROM OR RELATED TO THIS AGREEMENT SHALL BE LIMITED TO ACTUAL DIRECT DAMAGES AND SHALL NOT INCLUDE ANY OTHER LOSS OR DAMAGE, INCLUDING INDIRECT, SPECIAL, CONSEQUENTIAL, INCIDENTAL, EXEMPLARY OR PUNITIVE DAMAGES, INCLUDING LOST PROFITS, PRODUCTION, OR REVENUES, AND EACH PARTY RELEASES THE OTHER PARTY FROM ALL SUCH CLAIMS FOR LOSS OR DAMAGE OTHER THAN ACTUAL DIRECT DAMAGES; PROVIDED THAT THIS LIMITATION TO DIRECT DAMAGES SHALL NOT LIMIT THE PARTIES’ INDEMNIFICATION OBLIGATIONS UNDER Section 3.5(c), Section 7.3, AND Article 15.
