LIQUIDATED DAMAGES FOR FAILURE TO CLOSE Sample Clauses

LIQUIDATED DAMAGES FOR FAILURE TO CLOSE. IN THE EVENT THAT THE ESCROW AND THIS TRANSACTION FAIL TO CLOSE, AS A RESULT OF THE DEFAULT OF DEVELOPER IN THE PERFORMANCE OF ITS OBLIGATIONS UNDER THIS AGREEMENT, OR UPON A DEVELOPER EVENT OF DEFAULT, AS DEFINED IN THIS AGREEMENT, PRIOR TO THE CLOSE OF ESCROW, THE CITY AND THE DEVELOPER AGREE THAT THE CITY WILL SUSTAIN DAMAGES, AND THAT CITY'S ACTUAL DAMAGES WOULD BE IMPRACTICABLE OR EXTREMELY DIFFICULT TO DETERMINE. THE PARTIES THEREFORE AGREE THAT IN THE EVENT THAT ESCROW AND THIS TRANSACTION FAIL TO CLOSE AS A RESULT OF A DEVELOPER EVENT OF DEFAULT, AND THE CITY IS READY, WILLING AND ABLE TO PERFORM ITS OBLIGATIONS HEREUNDER, THE CITY, AS THE CITY'S SOLE AND EXCLUSIVE REMEDY, SHALL BE ENTITLED TO THE DEVELOPER DEPOSIT, AS LIQUIDATED DAMAGES AND AS CONSIDERATION FOR ENTERING INTO THIS AGREEMENT. THE PARTIES ACKNOWLEDGE THAT THE RESULTING DAMAGES WILL BE IMPRACTICAL OR EXTREMELY DIFFICULT TO ASCERTAIN, AND THEREFORE, THE PARTIES AGREE AFTER NEGOTIATION BETWEEN THEM THAT RETENTION OF THE DEVELOPER DEPOSIT, AS LIQUIDATED DAMAGES, WILL BE AN APPROPRIATE FORM OF COMPENSATION TO THE CITY. BY PLACING THEIR INITIALS IN THE SPACE BELOW, BOTH PARTIES AGREE TO THE LIQUIDATED DAMAGES SET FORTH ABOVE. IN THE EVENT ESCROW FAILS TO CLOSE AS A RESULT OF THE DEVELOPER EVENT OF DEFAULT AND THE CITY IS READY, WILLING AND ABLE TO PERFORM ITS OBLIGATIONS HEREUNDER, THEN (A) FOLLOWING THE CITY'S RECEIPT OF THE DEVELOPER DEPOSIT, THIS AGREEMENT AND THE RIGHTS AND OBLIGATIONS OF THE DEVELOPER AND CITY HEREUNDER AND THE ESCROW CREATED HEREBY SHALL TERMINATE (EXCEPT THOSE PROVISIONS SPECIFIED TO SURVIVE THE TERMINATION OF THIS AGREEMENT), AND (B) THE TITLE COMPANY SHALL, AND IS HEREBY AUTHORIZED AND INSTRUCTED TO, RETURN PROMPTLY TO THE DEVELOPER AND THE CITY ALL DOCUMENTS AND INSTRUMENTS TO THE PARTIES WHO DEPOSITED THE SAME. THE PAYMENT OF SUCH AMOUNT AS LIQUIDATED DAMAGES IS NOT INTENDED AS A FORFEITURE OR PENALTY WITHIN THE MEANING OF CALIFORNIA CIVIL CODE SECTIONS 3275 OR 3369, BUT IS INTENDED TO CONSTITUTE LIQUIDATED DAMAGES TO THE CITY PURSUANT TO CALIFORNIA CIVIL CODE SECTIONS 1671, 1676 AND 1677. THE CITY HEREBY WAIVES THE PROVISIONS OF CALIFORNIA CIVIL CODE SECTION 3389. THE CITY AND THE DEVELOPER ACKNOWLEDGE THAT THEY HAVE READ AND UNDERSTAND THE PROVISIONS OF THIS SECTION, AND BY THEIR INITIALS IMMEDIATELY BELOW AGREE TO BE BOUND BY ITS TERMS. CITY'S INITIALS: DEVELOPER'S INITIALS :
AutoNDA by SimpleDocs

Related to LIQUIDATED DAMAGES FOR FAILURE TO CLOSE

  • Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.

  • Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.

  • Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.

  • Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.

  • Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

  • Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.

  • Failure to Close (A) If Seller(s) fails to convey the property as provided in this contract: Buyer(s) may exercise legal remedies including suit for specific performances or damages. Agent may xxx Xxxxxx(s) to recover loss of commission. Agent may pay Xxxxxxx Money into a court of competent jurisdiction, or retain Xxxxxxx Money until directed to distribute the same by a court of competent jurisdiction.

  • Damages for Failure to Cut or Termination for Breach (a) In event of Purchaser’s failure to cut designated timber on portions of Sale Area by Termination Date or termination for breach under B9.31, Forest Service shall appraise remaining Included Timber, unless termination is under B8.22 or B8.34. Such appraisal shall be made with the standard Forest Service method in use at time of termination.

  • CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is September 26, 2016. The completion date for this contract is October 31, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.

  • OUR LIABILITY FOR FAILURE TO STOP PAYMENT If You order Us to place a stop payment on one of Your pre-authorized payments 3 business days or more before the transfer is scheduled, and We do not do so, We will be liable for losses or damages, to the extent provided by law. TRANSACTION SLIPS. Except for mail-in transactions and certain small-value transactions, You can get a receipt at the time You make any transaction to or from Your Account through the use of Your Card. When an electronic fund transfer has been made during any given month, You will receive a monthly statement to reflect all electronic fund transfers to or from Your Account during that statement period. In any case, You will receive a statement at least quarterly. FEES. We may assess reasonable charges against Your Account for transactions performed at electronic terminals. If so, We will specify any charges for these or other types of electronic transactions, including automatic transfers, on an accompanying pricing document. We will explain the charges to You when You open Your Account. You will be provided with a fee schedule, and other specified information after Your Account is established. Additional fee schedules are available at any of Our office locations. When You use an ATM not owned by Us, You may be charged a fee by the ATM operator, or any network used, and You may be charged a fee for a balance inquiry even if You do not complete a fund transfer.

Time is Money Join Law Insider Premium to draft better contracts faster.