Liquidated Damages for Product’s Weight. Guarantee [***]
Liquidated Damages for Product’s Weight Sample Clauses
Related to Liquidated Damages for Product’s Weight
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Supply Price In event BTC exercises the Supply Option, the Supply Agreement shall afford Auxilium supply terms for Year 1 that are not less favorable than the average price afforded to Auxilium by the Back-Up Suppliers for the year immediately preceding the Supply Date and supply terms for each successive year that are not less favorable than the average price afforded to Auxilium by the Back-Up Suppliers for each preceding year as applicable.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Delivery Point Once Manufacture of the Products has been completed, Contractor shall be responsible for delivering the Finished Goods FCA, (as defined in Incoterms (2000) published by the International Chamber of Commerce) and to a freight forwarder specified by Company in its Order, or otherwise approved by Company. “Delivery Point” as used in this Agreement shall mean the specific time and location that the Product is delivered to the shipper specified on the Order.
Volume (a) Buyer agrees to buy and ANC agrees to sell, in each calendar year during the term of this Agreement, 7 billion cans. Can bodies and ends shall be purchased by Buyer and supplied by ANC in substantially equal volumes.
Shipment If any of the Major Components associated with any Unit is not Shipped on or before (with the prior approval of the Buyer) the Scheduled Major Component Shipment Date set forth in Attachment 1 for reasons attributable to the Seller and not excused elsewhere in this Contract, the Seller shall pay as liquidated damages, and not as a penalty, a sum calculated in accordance with the table below for each Unit for each day of delay after the Scheduled Major Component Shipment Date as set forth in Attachment 1 until actual Shipment of the last Major Component for such Unit: Days after Scheduled Major Component Shipment Date Liquidated Damages (per day or partial day) *** *** *** *** *** *** Such liquidated damages, if any, shall be computed based on the date of Shipment of the last Major Component for a given Unit and such computations shall disregard any part of or accessory to the Major Component which may be shipped separately and arrive later unless such part of or accessory to the Major Component is necessary for the installation of the Major Component.
Disruption to Payment Systems etc If either the Agent determines (in its discretion) that a Disruption Event has occurred or the Agent is notified by the Borrower that a Disruption Event has occurred:
WHEXXXX xs xxxx of a plan of reorganization, RESTART PARTNERS, L.P., a Delaware Limited Partnership ("Restart"), may acquire an ownership interest in Elsinore Corporation ("Elsinore") or the Four Queens, Inc. ("FQI");
