List of Examples of Acts of God or Force Majeure Sample Clauses

List of Examples of Acts of God or Force Majeure. The following events are established, for the sake of example, as events of acts of God and force majeure, being established that the determination of occurrence of said events shall take into account the experience of Developer Lessor and the Construction Company, as well as the objective good faith: (i) general or partial strikes of federal, state or municipal employees and of the construction industry, to the extent that they provenly and directly affect the Work progress and/or the obtainment of any required licenses; (ii) unusual length or delay of any public facility concessionaire relating to (a) any activities that provenly and directly affect the Work progress, and/or (b) the new connections and/or expansion of the existing connections of water, sewage, telephone and electricity; (iii) unusual delay of the ports, such as strikes, “standard operation”, to the extent that the causal link is proven; (iv) state of war or disturbance of public order, provenly and directly affecting the Work progress; (v) rains causing an impact on the Work progress and abnormal meteorological phenomena preventing the Work performance within the established term; or earthquakes and other severe weather conditions; (vi) fires, explosions or claims preventing the work or reducing its pace, to the extent that they are not the liability of Developer Lessor, the Construction Company and/or its subcontractors; (vii) court decisions determining the interruption of the Work or preventing its performance as scheduled, to the extent that they are not caused by Developer Lessor, the Construction Company and/or its subcontractors; (viii) delay by the public authorities to issue any licenses and permits, as long as Developer Lessor has submitted all documents required by law in a timely manner; or (ix) changes in the federal, state or municipal law causing any hindrance or preventing the Work performance within the scheduled term.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to List of Examples of Acts of God or Force Majeure

  • SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence: a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.

  • Acts of God, etc FIIOC and FSC shall not be liable for delays or errors occurring by reason of circumstances beyond its control, including but not limited to acts of civil or military authority, national emergencies, work stoppages, fire, flood, catastrophe, acts of God, insurrection, war, riot, or failure of communication equipment of common carriers or power supply. In the event of equipment breakdowns beyond its control, FIIOC and FSC, as applicable, shall, at no additional expense to any Trust, take reasonable steps to minimize service interruptions and mitigate their effects but shall have no liability with respect thereto. FIIOC and FSC shall enter into and shall maintain in effect with appropriate parties one or more agreements making reasonable provision for emergency use of electronic data processing equipment.

  • Labor Disputes and Acts of God Neither the business nor the properties of the Borrower or any Subsidiary or any Guarantor are affected by any fire, explosion, accident, strike, lockout, or other labor dispute, drought, storm, hail, earthquake, embargo, act of God or of the public enemy, or other casualty (whether or not covered by insurance), materially and adversely affecting such business or properties or the operation of the Borrower or such Subsidiary or such Guarantor.

  • Acts of God In the event either party is unable to perform its obligations under the terms of this Management Agreement, despite having taken commercially reasonable precautions, because of acts of God, interruption of electrical power or other utilities, equipment or transmission failure or damage reasonably beyond its control, or other causes reasonably beyond its control, such party shall not be liable to the other for any damages resulting from such failure to perform or otherwise from such causes. The Manager and the Trust shall notify each other as soon as reasonably possible following the occurrence of an event described in this subsection.

  • Technical and Organisational Measures (1) Before the commencement of processing, the Supplier shall document the execution of the necessary Technical and Organisational Measures, set out in advance of the awarding of the Order or Contract, specifically with regard to the detailed execution of the contract, and shall present these documented measures to the Client for inspection. Upon acceptance by the Client, the documented measures become the foundation of the contract. Insofar as the inspection/audit by the Client shows the need for amendments, such amendments shall be implemented by mutual agreement. (2) The Supplier shall establish the security in accordance with Article 28 Paragraph 3 Point c, and Article 32 GDPR in particular in conjunction with Article 5 Paragraph 1, and Paragraph 2 GDPR. The measures to be taken are measures of data security and measures that guarantee a protection level appropriate to the risk concerning confidentiality, integrity, availability and resilience of the systems. The state of the art, implementation costs, the nature, scope and purposes of processing as well as the probability of occurrence and the severity of the risk to the rights and freedoms of natural persons within the meaning of Article 32 Paragraph 1 GDPR must be taken into account. [Details in Appendix 1] (3) The Technical and Organisational Measures are subject to technical progress and further development. In this respect, it is permissible for the Supplier to implement alternative adequate measures. In so doing, the security level of the defined measures must not be reduced. Substantial changes must be documented.

  • Force Majeure Exclusions 11.4.1 Force Majeure shall not include (i) any event or circumstance which is within the reasonable control of the Parties and (ii) the following conditions, except to the extent that they are consequences of an event of Force Majeure: a. Unavailability, late delivery, or changes in cost of the plant, machinery, equipment, materials, spare parts or consumables for the Power Project; x. Xxxxx in the performance of any contractor, sub-contractor or their agents; c. Non-performance resulting from normal wear and tear typically experienced in power generation materials and equipment; d. Strikes at the facilities of the Affected Party; e. Insufficiency of finances or funds or the agreement becoming onerous to perform; and f. Non-performance caused by, or connected with, the Affected Party’s: i. Negligent or intentional acts, errors or omissions; ii. Failure to comply with an Indian Law; or iii. Breach of, or default under this Agreement.

  • Technical and Organizational Measures The following sections define SAP’s current technical and organizational measures. SAP may change these at any time without notice so long as it maintains a comparable or better level of security. Individual measures may be replaced by new measures that serve the same purpose without diminishing the security level protecting Personal Data.

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.

  • Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!