ACTS OF GOD AND FORCE MAJEURE. All events that take place during the course of the performance of this AGREEMENT, of an unforeseeable nature and that provenly interfered with the progress of the works, shall be typified as Acts of God or force majeure and shall be cause for exemption from responsibility, such as:
ACTS OF GOD AND FORCE MAJEURE. Provided that the provisions of this Clause are complied with, neither of the Parties shall be held liable to the other Party due to non-fulfillment of any obligation (except pecuniary obligations) attributed to it under this Contract and insofar as such non-fulfillment is directly attributable to an event of force majeure or act of God under Brazilian Law, as defined by article 393, sole paragraph, of the Civil Code, including but not limited to (a) acts of wars, (whether declared or not), epidemics, sabotage, military actions or hostilities and acts of terrorism or the escalation thereof occurring after the date hereof; (b) regional or national strikes, work stoppages, slowdowns or lockouts of any trade category involved in production of the Product or adversely affecting abilities of either Party to comply with the terms and conditions of this Contract; (c) acts of God and inclement weather or such other atypical events of nature that are not predictable and/or the effects of which cannot be avoided by employing reasonable control measures; (d) accidents or emergency stoppages in order to prevent accidents that impede or restrict the operation and/or construction and/or expansion of installations related to the production of the Product; (e) any decision by an arbitration panel or court of law (even if preliminary and subject to further appeal), obtained by or granted in favor of third parties that prevents compliance with either Party's obligations under this Contract, except for litigation pertaining to right of first refusal on iron ore from Casa de Pedra Mine, included but not limited to the lawsuits listed in Attachment VII hereto (for the avoidance of doubt, those lawsuits shall not be considered nor deemed to be Force Majeure Event for every and all purposes of this Contract); (f) expropriation, or statement of eminent domain for expropriation purposes (“declaração de utilidade pública”), or any other restriction imposed by any public authority on either Party's assets adversely affecting either Party’s assets or abilities to comply with the terms and conditions of this Contract; (g) any changes in Applicable Law occurring after the date hereof which prevents either Party from complying with the terms and conditions of this Contract; and (h) any other circumstance, change, development, event or fact that is unpredictable or unavoidable by the affected Party and which prevents such Party from complying with the terms and conditions of this Contrac...
ACTS OF GOD AND FORCE MAJEURE. Landlord and Tenant, as applicable, shall not be required to perform any non-financial covenant or obligation in this Lease, or be liable in damages to the other party, so long as the performance or non-performance of the covenant or obligation is delayed, caused by, or prevented by an act of God or force majeure. For purposes of this Lease, an "act of God" or "force majeure" is defined as strikes, material or labor shortages, or restrictions on material or labor by any governmental authority, riots, floods, explosions, earthquakes, fire, storms, weather (including wet grounds or inclement weather which prevents construction), acts of the public enemy, wars, insurrections and any other cause not reasonably within the control of Landlord or Tenant, as applicable, and which by the exercise of due diligence Landlord or Tenant, as applicable, is unable, wholly or in part, to prevent or overcome.
ACTS OF GOD AND FORCE MAJEURE. If the Event must be cancelled or rescheduled due to an Act of God or some Force Majeure (including but not limited to: extreme weather, fire, famine, acts of war or terrorism, or an outbreak of an infectious disease) this Agreement shall immediately terminate and both Parties shall have no further obligation to the other except that each Party shall return to the other, any deposits, monies, or goods in their possessions.
ACTS OF GOD AND FORCE MAJEURE. All the unpredictable events occurred along the execution of this AGREEMENT that may provedly interfere in the rhythms of the works shall be characterized as an act of God or force majeure and considered as causes of liability exemption, such as:
ACTS OF GOD AND FORCE MAJEURE. Neither party shall be responsible to the other for delays in the fulfillment or non-fulfillment of their obligations due to force majeure, including, without limitation, a state of war, revolts, civil unrest, fires, illegal strikes, accidents, electrical failures, acts of governments or civil authorities and acts of God or other causes beyond the control of the CONTRACTING PARTY or THE CONTRACTOR. Notwithstanding the above, the parties shall make every effort to mitigate the effects of the act of God or force majeure in question.
ACTS OF GOD AND FORCE MAJEURE. Neither party shall be liable for any failure or delay in the performance of its obligations under this Agreement whereby such failure or delay is caused by an act of God, Force Majeure, riot or civil commotion, strike, lockout or other labor disturbances, fire, act and/or any other order of government, flood, war, peril of sea, or any other cause or peril whether of the same and/or of another nature beyond reasonable control.
ACTS OF GOD AND FORCE MAJEURE. The Provider shall not be responsible for any breach, damage or harm caused directly or indirectly to the User by any rally, civil commotion, war operation, invasion, military action or usurpation of power, sabotage, government regulations or controls, inability to obtain any material, service or financing, hurricanes, floods, fires or for any other reason derived from Acts of God or force majeure.
ACTS OF GOD AND FORCE MAJEURE. If at any working day the weather conditions or other circumstances (beyond LESSOR’s best efforts to control it) make materially impracticable LESSOR’s ability to perform its obligations under this Lease Agreement, It will be considered as a “Delay Day”. The parties hereto agree that LESSOR will be entitled to extend the working schedule for one working day for every Delay Day. Each party’s authorized representative will certify in writing the occurrence and additional dates granted if any. The parties hereto agree that they will conduct their best efforts in order to modify the work schedule to meet the new dates.
ACTS OF GOD AND FORCE MAJEURE. Neither party is bound to comply with the obligations of the present Contract in case of force majeure or acts of God, in which case the party that incurs in non compliance because of these causes, must notify the other party of the situation, and must renew the compliance of its obligations at the moment that the cause that originated the non compliance, ceases. Market fluctuations and a drop in the business volume of the CLIENT are not considered force majeure.
