Maintenance and Use of the Project Sample Clauses

Maintenance and Use of the Project. The Corporation shall cause the Project and the Encumbered Property to be maintained, preserved and kept in good repair and working order and condition and in as safe condition as its operations will permit and will make all necessary repairs, renewals, replacements and improvements thereof. Nothing in this Section shall obligate the Corporation to preserve, repair, renew or replace any part of the Project or the Encumbered Property no longer used or, in the judgment of its governing board, no longer useful in the conduct of its business, or prevent the Corporation from discontinuing the operation of any part of the Project, if in its reasonable judgment (evidenced, in the case of such a cessation other than in the ordinary course of business, by a determination by its governing board) such discontinuance is desirable in the conduct of its business and not disadvantageous in any material respect to the owners of the Bonds. The Corporation may make additions, alterations and changes to the Project so long as such additions, alterations and changes are made in compliance with the provisions of this Loan Agreement and will not result in a violation of the provisions of this Loan Agreement, and the Corporation may dispose of any part of the Project as permitted by this Loan Agreement.
AutoNDA by SimpleDocs

Related to Maintenance and Use of the Project

  • Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.

  • Project Maintenance The Local Government shall be responsible for maintenance of locally owned roads and locally owned facilities after completion of the work. The State shall be responsible for maintenance of the state highway system after completion of the work if the work was on the state highway system, unless otherwise provided for in existing maintenance agreements with the Local Government.

  • Preservation, Maintenance, and Protection of the Property Inspections. Borrower will not destroy, damage, or impair the Property, allow the Property to deteriorate, or commit waste on the Property. Whether or not Borrower is residing in the Property, Borrower must maintain the Property in order to prevent the Property from deteriorating or decreasing in value due to its condition. Unless Lender determines pursuant to Section 5 that repair or restoration is not economically feasible, Borrower will promptly repair the Property if damaged to avoid further deterioration or damage. If insurance or condemnation proceeds are paid to Lender in connection with damage to, or the taking of, the Property, Borrower will be responsible for repairing or restoring the Property only if Xxxxxx has released proceeds for such purposes. Lender may disburse proceeds for the repairs and restoration in a single payment or in a series of progress payments as the work is completed, depending on the size of the repair or restoration, the terms of the repair agreement, and whether Borrower is in Default on the Loan. Lender may make such disbursements directly to Borrower, to the person repairing or restoring the Property, or payable jointly to both. If the insurance or condemnation proceeds are not sufficient to repair or restore the Property, Borrower remains obligated to complete such repair or restoration. Lender may make reasonable entries upon and inspections of the Property. If Lender has reasonable cause, Xxxxxx may inspect the interior of the improvements on the Property. Lender will give Borrower notice at the time of or prior to such an interior inspection specifying such reasonable cause.

  • Maintenance and Use of Property Borrower shall cause the Property to be maintained in a good and safe condition and repair. The Improvements and the Personal Property shall not be removed, demolished or materially altered (except for normal replacement of the Personal Property or as permitted in the PETsMART Lease) without the consent of Lender. Except as provided in Section 3.8(f) hereof, Borrower shall promptly repair, replace or rebuild or cause to be repaired, replaced or rebuilt, any part of the Property which may be destroyed by any casualty, or become damaged, worn or dilapidated or which may be affected by any proceeding of the character referred to in Section 3.6 hereof and shall complete and pay for any structure at any time in the process of construction or repair on the Land. Borrower shall not initiate, join in, acquiesce in, or consent to any change in any private restrictive covenant, zoning law or other public or private restriction, limiting or defining the uses which may be made of the Property or any part thereof, provided, that Borrower shall be permitted to enter into easement agreements or grant rights of way so long as such agreements or grants do not reduce the value of the Property or impair its use, and so long as Borrower has delivered to Lender a title endorsement satisfactory to Lender with respect to such agreements and/or rights of way. If under applicable zoning provisions the use of all or any portion of the Property is or shall become a nonconforming use, Borrower will not cause or permit the nonconforming use to be discontinued or the nonconforming Improvement to be abandoned without the express written consent of Lender.

  • Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

  • USE AND MAINTENANCE (a) Lessee shall (1) use the Equipment solely in the continental United States and in the conduct of its business, for the purpose for which the Equipment was designed, in a careful and proper manner, and shall not permanently discontinue use of the Equipment; (2) operate, maintain, service and repair the Equipment, and maintain all records and other materials relating thereto, (A) in accordance and consistent with (i) the Supplier’s recommendations and all maintenance and operating manuals or service agreements, whenever furnished or entered into, including any subsequent amendments or replacements thereof, issued by the Supplier or service provider, (ii) the requirements of all applicable insurance policies, (iii) the Supply Contract, so as to preserve all of Lessee's and Lessor's rights thereunder, including all rights to any warranties, indemnities or other rights or remedies, (iv) all applicable laws, and (v) the prudent practice of other similar companies in the same business as Lessee, but in any event, to no lesser standard than that employed by Lessee for comparable equipment owned or leased by it; and (B) without limiting the foregoing, so as to cause the Equipment to be in good repair and operating condition and in at least the same condition as when delivered to Lessee hereunder, except for ordinary wear and tear resulting despite Lessee's full compliance with the terms hereof; (3) provide written notice to Lessor not less than thirty (30) days after any change of the location of any Equipment (or the location of the principal garage of any Equipment, to the extent that such Equipment is mobile equipment) as specified in the Schedule; and (4) not attach or incorporate the Equipment to or in any other property in such a manner that the Equipment may be deemed to have become an accession to or a part of such other property. (b) Within a reasonable time, Lessee will replace any parts of the Equipment which become worn out, lost, destroyed, damaged beyond repair or otherwise unfit for use, by new or reconditioned replacement parts which are free and clear of all Liens and have a value, utility and remaining useful life at least equal to the parts replaced (assuming that they were in the condition required by this Lease). Any modification or addition to the Equipment that is required by this Lease shall be made by Lessee. Title to all such parts, modifications and additions to the Equipment immediately shall vest in Lessor, without any further action by Lessor or any other person, and they shall be deemed incorporated in the Equipment for all purposes of the related Schedule. Unless replaced in accordance with this Section, Lessee shall not remove any parts originally or from time to time attached to the Equipment, if such parts are essential to the operation of the Equipment, are required by any other provision of this Lease or cannot be detached from the Equipment without materially interfering with the operation of the Equipment or adversely affecting the value, utility and remaining useful life which the Equipment would have had without the addition of such parts. Except as permitted in this Section, Lessee shall not make any material alterations to the Equipment that diminishes its use or value. (c) Upon forty-eight (48) hours' notice, Lessee shall afford Lessor and/or its designated representatives access to the premises where the Equipment is located for the purpose of inspecting such Equipment and all applicable maintenance or other records relating thereto at any reasonable time during normal business hours; provided, however, if a Default or Event of Default shall have occurred and then be continuing, no notice of any inspection by Lessor shall be required. If any discrepancies are found as they pertain to the general condition of the Equipment, Lessor will communicate these discrepancies to Lessee in writing. Lessee shall then have thirty (30) days to rectify these discrepancies at its sole expense. Lessee shall pay all expenses of a re-inspection by Lessor’s appointed representative, if corrective measures were required.

  • Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.

  • Maintenance of the Property Neither Broker nor Brokerage Firm is responsible for maintenance of the 324 Property nor are they liable for damage of any kind occurring to the Property, unless such damage is caused by their negligence or 325 intentional misconduct.

  • Repair and Maintenance 8.1 LANDLORD’S REPAIR AND MAINTENANCE. Landlord at its cost shall maintain the following: a. The structural parts of the building and other improvements, that are part of the leased premises which structural parts include the foundations, bearing and exterior walls, subflooring and roof. b. The unexposed electrical, plumbing and sewage systems, including, without limitation, those portions of the systems lying outside the premises. c. The Landlord shall have all snow and ice removed from the sidewalks leading to the premises as soon as practicable, and see that snow from the parking area is properly and reasonably removed and that all refuse and garbage is removed from the collection area. d. The Landlord shall maintain the common areas, parking areas, hallways and stairs and restrooms, in a safe, clean and orderly condition. 8.2 T’ENANT’S REPAIRS AND MAINTENANCE. Tenant at its cost shall perform the following: a. Any construction, modification and/or improvements made to the leased premise will be at the expense of the Tenant (unless otherwise agreed), and will require the approval of the Landlord. Any improvements or modifications performed by, or on behalf of, the Tenant will, at the option of the Landlord, remain as part of the Keuka Business Park at the conclusion of the lease term. b. Except as provided in paragraph 8.1 above, Tenant at its cost shall maintain the leased premises, including all janitorial care of the office and restroom facilities associated with this space, and at the expiration of the term of this Lease Agreement, or prior termination, Tenant shall surrender the leased premises to Landlord in the same condition as received, normal wear and tear, damage from the elements, fire or other casualty, damage Landlord is required to repair hereunder, or damage from the negligence or willful misconduct of Landlord, its agents or employees, excepted. c. Tenant also agrees to maintain outdoor areas affected by the operations of the business in an orderly fashion, including, but not limited to, stacking and disposal of pallets, trash and recycling areas, employee litter and damage to the facilities.

  • Installation and Maintenance Except for the bi‐directional and production metering equipment owned by the City, all equipment on Customer’s side of the delivery point, including the required disconnect device, shall be provided and maintained in satisfactory operating condition by Customer and shall remain the property and responsibility of the Customer. The City will bear no responsibility for the installation or maintenance of Customer’s equipment or for any damage to property as a result of any failure or malfunction thereof. The City shall not be liable, directly or indirectly for permitting or continuing to allow the interconnection of the Facility or for the acts or omissions of Customer or the failure or malfunction of any equipment of Customer that causes loss or injury, including death, to any party.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!