Manufacturing Difficulties and Shortages
Manufacturing Difficulties and Shortages Sample Clauses
Related to Manufacturing Difficulties and Shortages
Shortages Claims for shortages in the amount of Products shipped by Patheon will be dealt with by reasonable agreement of the parties.
Manufacturing (a) The Supplier shall without limitation be responsible, at no additional cost to the Purchaser, for: sourcing and procuring all raw materials for the Products; obtaining all necessary approvals, permits and licenses for the manufacturing of the Products; providing sufficient qualified staff and workers to perform the obligations under this Purchase Agreement; implementing and maintaining effective inventory and production control procedures with respect to the Products; and handling other matters as reasonably requested by the Purchaser from time to time. (b) The Supplier shall not change any process, material, component, packaging or manufacturing location without the Purchaser’s express prior written approval.
Raw Materials A. Catalent shall procure Raw Materials only from vendors that are approved in writing by Palatin or otherwise qualified in accordance with the provisions of the Quality Agreement. Catalent shall be responsible for procuring Raw Materials as necessary to meet the Firm Commitment. Catalent shall not be liable for any delay in delivery of Product if (i) Catalent is unable to obtain, in a timely manner, a particular Raw Material necessary for Processing and (ii) Catalent placed orders for such Raw Materials promptly following receipt of Palatin’s Firm Commitment. In the event that any Raw Material becomes subject to purchase lead time beyond the Firm Commitment time frame, the parties will negotiate in good faith an appropriate amendment to this Agreement, including Clause 4.2. B. In certain instances, Palatin may require a specific supplier, manufacturer or vendor (“Vendor”) to be used for Raw Material. In such an event, (i) such Vendor will be identified in the Specifications and (ii) the Raw Materials from such Vendor shall be deemed Palatin-supplied Materials for purposes of this Agreement. If the cost of the Raw Material from any such Vendor (other than a Vendor specified in the Specifications as of the Effective Date) is greater than Catalent’s costs for the same raw material of equal quality from other vendors, Catalent shall add the difference between Catalent’s cost of the Raw Material and the Vendor’s cost of the Raw Material to the Unit Pricing. Palatin will be responsible for all reasonable, out-of-pocket costs incurred by Catalent associated with qualification of any such Vendor who has not been previously qualified by Catalent. C. In the event of (i) a Specification change for any reason, (ii) obsolescence of any Raw Material or (iii) termination or expiry of this Agreement, Palatin shall bear the cost of any unused Raw Materials (including packaging), so long as Catalent (a) purchased such Raw Materials in quantities consistent with Palatin’s then current Firm Commitment and any minimum purchase obligations required by the vendor and (b) used commercially reasonable efforts to mitigate such costs by using any such unused Raw Materials in the manufacture of other products.
Adverse Events Subsequent to the date hereof, there shall not have occurred any of the following: (i) a suspension or material limitation in trading in securities generally on the New York Stock Exchange, the NASDAQ National Market or the NASDAQ Global Market, (ii) a general moratorium on commercial banking activities in the People’s Republic of China or New York, (iii) the outbreak or escalation of hostilities involving the United States or the People’s Republic of China or the declaration by the United States or the People’s Republic of China of a national emergency or war if the effect of any such event specified in this clause (iii) in your reasonable judgment makes it impracticable or inadvisable to proceed with the public offering or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus, or (iv) such a material adverse change in general economic, political, financial or international conditions affecting financial markets in the United States or the People’s Republic of China having a material adverse impact on trading prices of securities in general, as, in your reasonable judgment, makes it impracticable or inadvisable to proceed with the public offering of the Shares or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus.
Manufacturing Services Jabil will manufacture the Product in accordance with the Specifications and any applicable Build Schedules. Jabil will reply to each proposed Build Schedule that is submitted in accordance with the terms of this Agreement by notifying Company of its acceptance or rejection within three (3) business days of receipt of any proposed Build Schedule. In the event of Jabil’s rejection of a proposed Build Schedule, Jabil’s notice of rejection will specify the basis for such rejection. When requested by Company, and subject to appropriate fee and cost adjustments, Jabil will provide Additional Services for existing or future Product manufactured by Jabil. Company shall be solely responsible for the sufficiency and adequacy of the Specifications [***].
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Cash Shortages No employee may be required to make up cash register shortages unless he or she is given the privilege of checking the money and daily receipts upon starting and completing the work shift, and unless the employee has exclusive access to the cash register during the work shift and unless cash is balanced daily, except as specified below. No employee may be required to make up register shortages when Management exercises the right to open the register during the employee's work shift, unless the register is opened in the presence of the employee and the employee is given the opportunity to verify all withdrawals and/or deposits. No employee shall be held responsible for cash shortages unless he or she has exclusive access to his or her cash.
Materials and Supplies The cost of materials and supplies is allowable. Purchases should be charged at their actual prices after deducting all cash discounts, trade discounts, rebates, and allowances received. Withdrawals from general stores or stockrooms should be charged at cost under any recognized method of pricing, consistently applied. Incoming transportation charges are a proper part of materials and supply costs.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Labeling Upon request, Lessee will xxxx the Equipment indicating Lessor's interest with labels provided by Lessor. Lessee will keep all Equipment free from any other marking or labeling which might be interpreted as a claim of ownership.
