Contract Price and Payment In consideration of the Contractor's due and proper performance of its obligations under the Contract, the Contractor may charge the Authority or, as the case may be, any Beneficiary the Contract Price in accordance with this Clause 6. The only sums payable by the Authority or any Beneficiary to the Contractor for the provision of the Services shall be the Contract Price. All other costs, charges, fees and expenses of whatever kind arising out of or in connection with the Contract shall be the responsibility of the Contractor. In accordance with the Contract, where the Contractor is required to provide Deliverables, the Authority or any Beneficiary shall be entitled to withhold payment of the Contract Price pending receipt and acceptance of the Deliverables in accordance with the Specification. Unless otherwise agreed in writing by the Authority or any Beneficiary and the Contractor, within 15 days of the end of each calendar month, the Contractor shall invoice the Authority or, as the case may be, any Beneficiary for any Services provided by the Contractor in that calendar month. Such invoice shall be rendered on the Contractor's own invoice form clearly marked with the Authority’s or the Beneficiary's order number (if any). Invoices must show the period to which they relate and the aspects of the Services for which payment is claimed together with the agreed charging rates and any other details the Authority or the Beneficiary may require. Failure to provide such information will entitle the Authority or the Beneficiary to delay payment of the Contract Price until such information is provided. Subject to Clauses 6.3 and 6.6, the Authority or any Beneficiary shall pay any invoice submitted by the Contractor in accordance with Clause 6.4 within 30 days of receipt by the Authority or the Beneficiary of such invoice. The Authority or the Beneficiary shall pay such invoice(s) by BACS (Bank Automated Clearing System) if it so chooses or any alternate means as agreed between the Authority or the Beneficiary and the Contractor. The Authority and any Beneficiary shall be entitled to deduct from any monies due or to become due to the Contractor any monies owing to the Authority or the Beneficiary from the Contractor. Where the performance of the Contractor does not meet the required standard then a deduction as set out in the Specification or as agreed by the Parties may be made. Except where otherwise stated in the Order, the Contract Price is exclusive of VAT which shall be payable, if applicable, by the Authority or any Beneficiary in addition to such Contract Price. The invoice provided to the Authority or any Beneficiary by the Contractor in accordance with Clause 6.4 shall show the VAT calculations separately. The Contractor will keep accurate books and records in relation to the provision of the Services in accordance with sound and prudent financial management. All such books and records shall be made available to the Authority at regular intervals of not less than quarterly. In the event of the Authority or any Beneficiary breaching Clause 6.5, the Contractor shall be entitled to charge interest on the outstanding amount owed by the Authority or such Beneficiary in accordance with the Late Payment of Commercial Debts (Interest) Act 1998. Subject to Clauses 6.12 and 6.13, the Contract Price shall not be subject to any increase whatsoever by the Contractor during the Contract Period. In the event that the Contract is varied under Clauses 22 or 23 in such a way as to affect the Contract Price and if agreement between the Parties cannot be reached on the adjustment to the Contract Price within 3 months both Parties shall jointly act to resolve the dispute in accordance with Clause 24. If the adjusted Contract Price is not so agreed or certified until after such variation has taken effect, the Authority or any Beneficiary shall continue to pay the Contractor at the rate current prior to the variation but shall pay to the Contractor or be entitled to recover from the Contractor as the case may be such sum if any as is equal to the difference between the amount which should have been paid in accordance with the adjusted Contract Price and the amount which was actually paid. In the event that the Contract ends or is terminated otherwise than at the end of a complete year, the sum payable by the Authority or any Beneficiary under Clause 6 shall be one twelfth of the annual sum which would otherwise have been payable for the complete year for each completed month.
Price Schedule, Payment Terms and Billing, and Price Adjustments (a) Price Schedule: Price Schedule under this Contract is set forth in Exhibit B.
ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.
WARRANTY-PRICE A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase. B. The Contractor certifies that the prices in the Offer have been arrived at independently without consultation, communication, or agreement for the purpose of restricting competition, as to any matter relating to such fees with any other firm or with any competitor. C. In addition to any other remedy available, the City may deduct from any amounts owed to the Contractor, or otherwise recover, any amounts paid for items in excess of the Contractor's current prices on orders by others for like deliverables under similar terms of purchase.
Supply Price The Initial Term “Supply Price” for the “Monthly Fixed Price Volume” set forth on Exhibit A shall be $[______]/MWh for the first [***] years of the Initial Term, and thereafter shall be the then-current market price as mutually agreed by Customer and Supplier prior to the end of the [***] year. The Extension Term Supply Price, if any, will be the then-current market price as mutually agreed by Customer and Supplier prior to entering into the Extension Term. Supplier and Customer may agree to fix the Supply Price for one or more periods during the Term that individually and in total are shorter than the full Term. Exhibit A sets forth the hourly delivery volume for which the Energy Price will be fixed during each month of the Term to take into account the phase-in of the facility which is expected to progress at a rate of approximately [***]MW per month (the “Monthly Fixed Price Volume”). Supplier represents that Supplier has used commercially reasonable efforts to set such Supply Price at approximately [***]% discount to the forward price at which Supplier xxxxxx its delivery obligations under this Transaction Confirmation with respect to any financial or physical energy supply arrangement intended to cover the Monthly Fixed Price Volume, the settlement index (ERCOT North Load Zone), and this Transaction Confirmation term. The [***]% discount shall be revised to take into account any physical or software limitations originating from Customer and limiting Supplier’s ability to curtail 100% of the load at the Data Center. Exhibit A also sets forth the minimum load that Customer has designated as not subject to economic curtailment (“Non-Curtailable Load”), which represents, among other things, the Motor Control Center (MCC), and other essential server and administrative load. Customer and Supplier can, in the context of the immediately preceding sentence, agree on a lesser than [***]% discount with respect to the Supply Price to account for Supplier’s incremental cost of providing a fixed Supply Price for Non-Curtailable Load.
Packaging Materials and Containers for Retail Sale 1. When packaging materials and containers in which a good is packaged for retail sales are classified in the Harmonized System with the good, they shall not be taken into account in determining whether all non-originating materials used in the production of the good undergo the applicable change in tariff classification set out in Annex 4.03. 2. When the good is subject to a requirement of regional value content, the value of these packaging materials and containers shall be taken into account as originating or non-originating materials, as the case may be, in calculating the regional value content of the good.
C1 Contract Price In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
