Method of Payment - Construction Phase Sample Clauses

Method of Payment - Construction Phase. 1. Refer to the Exhibit H, General Conditions Of The Contract For Construction (Document 00700).
Sample 1Sample 2Sample 3See All (18)
AutoNDA by SimpleDocs
Method of Payment - Construction Phase. Refer to the Exhibit H, General Conditions Of The Contract For Construction (Document 00700). Invoices furnished by the Contractor under this Agreement must be in the form specified above and must be submitted for approval to: Project Manager Office of Court Construction and Management Administrative Office of the Courts 0000 Xxxxxxx Xxxx Xxxxx, Xxxxx 000 Xxxxxxxxxx, XX 00000 The AOC will endeavor to pay invoices within thirty (30) days after receipt of a correct, itemized invoice. In no event shall the AOC be liable for interest or late charges for any late payments. Payment shall be made by the AOC to the Contractor at the address specified on the invoice. The AOC may withhold full or partial payment to the Contractor in any instance in which the Contractor has failed or refused to satisfy any material obligation provided for under this Agreement.
Sample 1See All (4)
Method of Payment - Construction Phase. Refer to the Exhibit H, General Conditions Of The Contract For Construction (Document 00700). Invoices furnished by the Contractor under this Agreement must be in the form specified above and must be submitted for approval to: @Project Manager Project Manager Office of Court Construction and Management Judicial Council of California Administrative Office of the Courts _____________________ ______________________ The AOC will endeavor to pay invoices within thirty (30) days after receipt of a correct, itemized invoice. In no event shall the AOC be liable for interest or late charges for any late payments. Payment shall be made by the AOC to the Contractor at the address specified on the invoice. The AOC may withhold full or partial payment to the Contractor in any instance in which the Contractor has failed or refused to satisfy any material obligation provided for under this Agreement.
Sample 1Sample 2Sample 3
Method of Payment - Construction Phase. Refer to the Exhibit H, General Conditions Of The Contract For Construction (Document 00700). Invoices furnished by the Contractor under this Agreement must be in the form specified above and must be submitted for approval to: Project Manager Office of Court Construction and Management Administrative Office of the Courts Court of Appeals, Fifth Appellate District 0000 Xxxxxxx Xxxxxx, Xxxx 000 Xxxxxx, XX 00000 The AOC will endeavor to pay invoices within thirty (30) days after receipt of a correct, itemized invoice. In no event shall the AOC be liable for interest or late charges for any late payments. Payment shall be made by the AOC to the Contractor at the address specified on the invoice. The AOC may withhold full or partial payment to the Contractor in any instance in which the Contractor has failed or refused to satisfy any material obligation provided for under this Agreement.
Sample 1
Method of Payment - Construction Phase. Refer to the General Conditions Of The Contract For Construction (Document 00 70 00). Invoices furnished by the Contractor under this Agreement must be in the form specified above and must be submitted for approval to: Xxxxxx Xxxxxx, AOC Project Manager Judicial Council of California AOC/OCCM/DCS 0000 Xxxxx Xxxxxxx Xxxxxx XXX-000 Xxxxxxx, Xxxxxxxxxx 00000-0000 The AOC will endeavor to pay invoices within thirty (30) days after receipt of a correct, itemized invoice. In no event shall the AOC be liable for interest or late charges for any late payments. Payment shall be made by the AOC to the Contractor at the address specified on the invoice. The AOC may withhold full or partial payment to the Contractor in any instance in which the Contractor has failed or refused to satisfy any material obligation provided for under this Agreement.
Sample 1

Related to Method of Payment - Construction Phase

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!