Missed Repair Appointments. Definition: Exclusions: Report Dimensions: Sub-Metrics:
Missed Repair Appointments Sample Clauses
Related to Missed Repair Appointments
Required Repairs Borrower shall perform all of the repairs (on an Individual Property by Individual Property basis) at the applicable Individual Properties, as more particularly set forth on Schedule 5.1.32 hereto (such repairs hereinafter referred to as “Required Repairs”) (i) in compliance with all applicable Legal Requirements, (ii) in a Lien-free, good and workmanlike manner and (iii) prior to the date set forth on Schedule 5.1.32 with respect to such Required Repairs (each such date, a “Required Repair Deadline”). It shall constitute an Event of Default if Borrower does not complete each Required Repair by the applicable Required Repair Deadline, provided that, if Borrower shall have been unable to complete a Required Repair by the applicable Required Repair Deadline, after using commercially reasonable efforts to do so, including, without limitation, if caused by delays due to weather or force majeure, such Required Repair Deadline shall be automatically extended solely as to such Required Repair to permit Borrower to complete such Required Repair so long as Borrower is at all times thereafter diligently and expeditiously proceeding to complete the same. Notwithstanding the foregoing, to the extent any Required Repair is the responsibility of a Tenant pursuant to a Lease, Borrower shall be obligated only to use commercially reasonably efforts to have such Tenant complete such Required Repair on or prior to the Required Repair Deadline.
Alterations and Repairs Lessee shall not make or permit to be made any other alterations, additions, improvements, or changes (collectively, “Alterations”), in the premises, without Lessor’s prior written approval, which approval Lessor may withhold in Lessor’s sole discretion. Subject to the services to be rendered by Lessor as set forth in the Schedule, Lessee shall, at Lessee’s expense, keep the premises generally consistent with the standard maintained by other tenants of premises in the Building during the tenancy. If Lessee does not make repairs promptly and adequately, Lessor may, but need not, make repairs, and Lessee shall pay promptly the reasonable cost thereof. At any time or times, Lessor, either voluntarily or pursuant to governmental requirement, may, at Lessor’s expense, make repairs, alterations, or improvements in or to the Building or any part thereof, including the premises, and, during such operations Lessor may close entrances, doors, corridors, elevators, or other facilities, all without any liability to Lessee or deduction of rent by reason of interference, inconvenience, or annoyance; provided that Lessee shall have access to the premises sufficient for conduct of Lessee’s business. Lessor shall not be liable to Lessee for any expense, injury, loss, or damage resulting from work done in or upon, or the use of, any adjacent or nearby building, land, street, or alley, provided that Lessor makes a reasonable effort to minimize the disruption to Lessee’s business. In the event Lessee requests that repairs, alterations, decorating, or other work in the premises be made during periods other than ordinary business hours, Lessee shall pay Lessor for overtime and other additional expenses incurred because of such request.
Good Repair The Borrower will, and will cause each of its Subsidiaries to, ensure that its material properties and equipment used or useful in its business in whomsoever's possession they may be, are kept in good repair, working order and condition, normal wear and tear excepted, and that from time to time there are made in such properties and equipment all needful and proper repairs, renewals, replacements, extensions, additions, betterments and improvements, thereto, to the extent and in the manner customary for companies in similar businesses.
Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Maintenance & Repairs 5.1 Lessee shall at all times be responsible for maintaining at its own expense the leased premises in a clean, orderly and safety condition, except as hereinafter provided. Lessee shall be responsible, at its own expense, to clean and maintain all trade fixtures, machinery and equipment furnished by Lessee within the leased premises. Lessee shall be responsible to deposit normal office waste and rubbish at a location at the Central School as designated by Lessor. 5.2 Lessee shall be responsible to perform all repairs the need for which is caused by Xxxxxx's use of the premises except that Lessor shall be responsible to perform major repairs of a structural nature. Lessor shall be responsible to arrange for removal of waste and rubbish from the location designated as the deposit location for lessees. All costs incurred by Lessor pursuant to the obligations of this Paragraph shall be included within "operating costs". 5.3 Lessor shall provide custodian services for the common areas of Central School. Costs incurred by Lessor in providing such custodian services shall be included within "operating costs".
Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.
Maintenance, Alteration and Repair (a) Resident is responsible for and agrees to take good care of the premises, fixtures and all common areas. Resident may not remove any of Owner’s property and will not perform any repairs, upgrades, painting, wallpapering, electric changes or other alterations of the premises without prior written consent from Owner. Resident will be responsible for damage from waste stoppages caused by foreign or improper objects or improper use in lines serving bathrooms, damage to fixtures, appliances, doors, windows, screens, damage from water faucets left on or from doors left open, and repairs or replacements to alarm devices necessitated by misuse or damage by Resident and/or guests. Extraordinary appliances or furnishings such as satellite dishes, hot tubs, pool tables, water beds or high utility-consuming devices may not be installed or placed on the premises or anywhere at the Property without Owner’s prior written consent, in its sole discretion. SAMPLE (b) In the case of a malfunction of any utilities or damage by fire, water or similar cause, or any water leak, suspected mold or microbial growth, electrical problem, broken glass, broken lock or any other condition that Resident reasonably believes poses a hazard to health and safety, Resident must promptly notify Owner in writing. Owner will act with reasonable time and diligence in making repairs and reconnections; Resident may not withhold or reduce payment of rent or other charges during such time. Maintenance and repair requested by Resident will generally be performed between 8am and 8pm, unless the work is considered an emergency, in which case work may take place at any time. Owner may temporarily disconnect equipment or utilities to avoid property damage and/or to perform repairs requiring such interruption, in Owner’s sole discretion. Owner will not be liable for any inconvenience, discomfort, disruption or interference with Resident use of the premises because of ongoing repairs, alterations or improvements to the Property or any apartment. (c) Following move-in, Resident is responsible for providing and changing all light bulbs and batteries (for smoke detectors and remote controls) in the assigned apartment. A written maintenance report requesting assistance in changing these items may be submitted for maintenance staff assistance, with extra charges payable by Resident as applicable per Owner’s published rates. From time to time, maintenance staff may enter the assigned apartment with or without notice to inspect and change furnace filters and to provide pest control.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Maintenance and Repairs (1) Except for matters specified under Paragraph 4 above and Paragraph 8A(3) below as being Landlord's obligation, Tenant shall, at Tenant's sole cost and expense, maintain the Premises in good order, condition and repair, ordinary wear and tear and damage by fire and casualty excepted, including: the interior surfaces of the ceilings, walls and floors; all doors and interior windows; furnishings installed within the Premises; all equipment installed by or at the expense of Tenant; and all plumbing, heating, ventilating, electrical and lighting facilities and fixtures; all landscaping, parking lots, fences and signs located within the Premises. (2) In the event that Tenant fails to maintain the Premises in good order, condition and repair as required under this Lease, Landlord shall give Tenant prior written notice to do such acts as are required to so maintain the Premises. In the event that Tenant fails to commence such work within 30 days after written demand by Landlord, and diligently prosecute it to completion, then Landlord shall have the right, but shall not be obligated, to do such acts and expend such funds at the expense of Tenant as are reasonably required to perform such work. Landlord shall have no liability to Tenant for any reasonable damage, inconvenience or interference with Tenant's use of the Premises as a result of performing any such work. (3) Landlord will maintain, repair and replace all structural components of the Premises and the roof of the Building, and if a repair, replacement or alteration or other change would be considered a capital improvement or replacement to the Premises under generally accepted accounting principles, then it shall be Landlord's responsibility to promptly make and pay for such repair, replacement, alteration or other change. The cost of any such capital improvement shall be amortized over the useful life of such item and Tenant agrees to pay its percentage share (which shall be determined by dividing the square footage of the Building by the square footage of all buildings benefitted by such improvement, including the Building) of the annual amortized amount. Such payment will be made by Tenant as set forth in Paragraph 4 above. Landlord shall do all acts required to comply with all applicable laws, ordinances, regulations and rules of any public authority relating to the Premises, except to the extent that the foregoing are solely a result of Tenant's use of the Premises. Tenant shall do all acts required to comply with all applicable laws, ordinances, regulations and rules of any public authority relating solely to Tenant's use of the Premises. If a repair is required as a result of Tenant's negligence and such repair cost is not covered by insurance proceeds, Tenant will pay for the cost of such repair. Notwithstanding anything in this Lease to the contrary, in the event that the need for repairs or the making of repairs (or both) which Landlord is obligated to effect at Landlord's expense renders a material portion of the Premises unusable for more than three consecutive business days, then Tenant shall be entitled to an abatement of rent commencing with the fourth business day that the same are unusable; provided, however, that Tenant shall not be entitled to a pro rata abatement of rent under the foregoing due to unusability (i) caused directly or indirectly by any act or omission of Tenant or any of Tenant's servants, employees, agents, contractors, visitors or licensees, (ii) where Tenant makes a decoration, alteration, improvement or addition which directly causes such unusability, or (iii) where the repair in question is one which Tenant is obligated to furnish under the provisions of this Lease.
