Specific Limitations on Indemnification Notwithstanding anything in this Agreement to the contrary, the Corporation shall not be obligated under this Agreement to make any payment to Indemnitee with respect to any Proceeding:
(a) To the extent that payment is actually made to Indemnitee under any insurance policy, or is made to Indemnitee by the Corporation or an affiliate otherwise than pursuant to this Agreement. Notwithstanding the availability of such insurance, Indemnitee also may claim indemnification from the Corporation pursuant to this Agreement by assigning to the Corporation any claims under such insurance to the extent Indemnitee is paid by the Corporation;
(b) Provided there has been no Change in Control, for Liabilities in connection with Proceedings settled without the Corporation’s consent, which consent, however, shall not be unreasonably withheld;
(c) For an accounting of profits made from the purchase or sale by Indemnitee of securities of the Corporation within the meaning of section 16(b) of the Securities Exchange Act of 1934, as amended (the “Exchange Act”), or similar provisions of any state statutory or common law;
(d) To the extent it would be otherwise prohibited by law, if so established by a judgment or other final adjudication adverse to Indemnitee; or
(e) In connection with a Proceeding commenced by Indemnitee (other than a Proceeding commenced by Indemnitee to enforce Indemnitee’s rights under this Agreement) unless the commencement of such Proceeding was authorized by the Board of Directors.
Indemnification and Limitation on Liability 1. Seller agrees to indemnify and hold harmless JPMS and its directors, officers, employees and affiliates from and against all claims, losses, damages and liabilities (including without limitation, any legal or other expenses reasonably incurred in connection with defending or investigating any such action or claim) arising out of or attributable to JPMS’s actions taken or not taken in compliance with this Sales Plan or arising out of or attributable to any breach by Seller of this Sales Plan (including Seller’s representations and warranties hereunder) or any violation by Seller of applicable laws or regulations. This indemnification shall survive termination of this Sales Plan. Notwithstanding the foregoing, Seller shall have no indemnification obligation to the extent any claims, losses, damages or liabilities are due to the gross negligence, recklessness or willful misconduct of JPMS or any other indemnified person.
2. Notwithstanding any other provision hereof, JPMS shall not be liable to Seller for: (a) special, indirect, punitive, exemplary or consequential damages, or incidental losses or damages of any kind, even if advised of the possibility of such losses or damages or if such losses or damages could have been reasonably foreseen; or (b) any failure to perform or to cease performance or any delay in performance that results from a cause or circumstance that is beyond its reasonable control, including but not limited to failure of electronic or mechanical equipment, strikes, failure of common carrier or utility systems, severe weather, market disruptions or other causes commonly known as “acts of God”.
Limitations on Indemnification (a) Notwithstanding the provisions of Section 7.2, Seller shall not be required to indemnify or hold harmless any of Buyer Indemnified Parties on account of any Buyer Indemnified Losses under Section 7.2 unless the liability of Seller in respect of such Buyer Indemnified Loss, when aggregated with the liability of Seller in respect of all Buyer Indemnified Losses under Section 7.2, exceeds $250,000 (the “Threshold Amount”), in which event Buyer Indemnified Parties shall be entitled to indemnification from Seller in an amount equal to the aggregate amount of the Buyer Indemnified Losses. In no event shall the aggregate liability of Seller under Section 7.2 of this Agreement exceed $2,000,000 (the “Ceiling Amount”). Notwithstanding the foregoing, neither the Threshold Amount nor the Ceiling Amount shall be applicable to indemnification pursuant to Section 7.2(iii) or Section 7.2(iv) or with respect to the representations and warranties of Seller set forth in the first and second sentences of Section 3.2, Section 3.2(e), Section 3.8 and Section 3.10. Seller may satisfy any obligations arising pursuant to this Article 7 in any combination of cash or the surrender of Consideration Units for redemption (valued at $21.00 per Consideration Unit); provided that, Seller must provide written notice to Buyer of the intent to make a payment (in whole or in part) by surrendering Consideration Units for redemption at least five business days prior to the due date of any such payment.
(b) Notwithstanding the provisions of Section 7.3, Buyer shall not be required to indemnify or hold harmless any of the Seller Indemnified Parties on account of any Seller Indemnified Loss under Section 7.3 unless the liability of Buyer in respect of such Seller Indemnified Loss, when aggregated with the liability of Buyer in respect of all Seller Indemnified Losses under Section 7.3, exceeds the Threshold Amount, in which event Seller Indemnified Parties shall be entitled to indemnification from Buyer in an amount equal to the aggregate amount of the Seller Indemnified Losses exceed the Threshold Amount. In no event shall Buyer be liable under Section 7.3 of this Agreement for any amount in excess of the Ceiling Amount. Notwithstanding the foregoing, neither the Threshold Amount nor the Ceiling Amount shall be applicable to indemnification pursuant to Section 7.3(iii) or Section 7.3(iv) or with respect the representations and warranties of Buyer set forth in Section 4.6.
(c) The amount of indemnity claim hereunder shall be reduced by the amount of any tax benefit actually realized by the Buyer Indemnified Parties or the Seller Indemnified Parties as a result of such claim.
(d) The amount of any indemnity claim hereunder shall be reduced by the amount of any proceeds of insurance actually received by the Buyer Indemnified Parties or Seller Indemnified Parties, as the case may be, in connection with such claim; provided, however, the foregoing shall not bar any insurance company that has made any payment to a Buyer Indemnified Party or Seller Indemnified Party from pursuing its lawful rights to subrogation.
(e) Except as set forth in Section 9.6(b), the parties agree that the indemnification provisions in this Article 7 shall be the exclusive remedy of the parties with respect to any claims between the parties concerning this Agreement and the other Transaction Agreements.
Compensation and Limitation of Liability 14 Section 1.
Limitations on Indemnification Obligations The rights of the Indemnified Parties to indemnification pursuant to the provisions of Section 7.2(a) and Section 7.2(b) are subject to the following provisions:
(a) None of the Indemnified Parties shall be entitled to recover for any particular Loss pursuant to Section 7.2(a)(i) or Section 7.2(b)(i) (except in the case of Fraud) unless such Loss equals or exceeds $10,000 (and no such Loss less than $10,000 shall be applied against the Deductible).
(b) The Indemnified Parties shall not be entitled to recover Losses pursuant to Section 7.2(a)(i) or Section 7.2(b)(i) (except in the case of Fraud) until the total amount which the Indemnified Parties would recover under Section 7.2(a)(i) or Section 7.2(b)(i), as applicable, in the aggregate (as limited by the other provisions hereof), but for this Section 7.4(b), exceeds $1,192,500 (the “Deductible”), in which case the applicable Indemnified Parties shall only be entitled to recover Losses in excess of such amount, subject to the other limitations herein.
(c) Except, in each case, in the case of Fraud, (i) the maximum liability of Seller to the Purchaser Indemnitees with respect to any Losses of the Purchaser Indemnitees indemnifiable pursuant to Section 7.2(a)(i) shall not exceed $1,192,500 and (ii) the maximum liability of Seller or Purchaser, as applicable, for indemnifiable Losses pursuant to this Article VII shall not exceed the Aggregate Purchase Price.
(d) The amount of any and all Losses indemnifiable hereunder shall be determined net of any amounts actually recovered by the Indemnified Parties under insurance policies (excluding, in the case of the Purchaser Indemnitees, the Representation and Warranty Insurance Policy) or other collateral sources (such as contractual indemnities of any Person which are contained outside of this Agreement) with respect to such Losses (which amounts actually recovered by the Indemnified Parties shall be calculated, in each case, net of any reasonable out-of-pocket costs and any Taxes incurred in connection with such recovery). In any case where a Purchaser Indemnitee actually recovers, under insurance policies (excluding, in the case of the Purchaser Indemnitees, the Representation and Warranty Insurance Policy) or from other collateral sources, any amount in respect of a matter for which such Indemnified Party was previously indemnified hereunder, such Indemnified Party shall promptly pay over to the Responsible Party a refund equal to the amount so recovered (after deducting therefrom the amount of the reasonable out-of-pocket costs and expenses and any Taxes incurred in connection with such recovery), if and solely to the extent that such amount of recovery would have reduced the amount to which the Indemnified Party would have been entitled pursuant to the first sentence of this Section 7.4(d), but not in excess of the aggregate amount previously paid to the Indemnified Parties hereunder in respect of such matter.
(e) The Purchaser Indemnitees shall use commercially reasonable efforts to recover under the Representation and Warranty Insurance Policy, to the extent available and subject to applicable retention and other coverage limitations thereunder, for any Losses for Indemnified Taxes pursuant to Section 7.2(a)(iv) or for any Losses pursuant to Section 7.2(a)(ii) prior to seeking indemnification from Seller under this Agreement; provided that nothing in this Section 7.4(e) shall limit the Purchaser Indemnitees’ rights to indemnification pursuant to Section 7.2(a)(iv) or pursuant to Section 7.2(a)(ii) to the extent that recovery is not available under the Representation and Warranty Insurance Policy for any reason with respect to all or any portion of such Losses. The amount of any and all indemnifiable Losses for Indemnified Taxes pursuant to Section 7.2(a)(iv) or for any indemnifiable Losses pursuant to Section 7.2(a)(ii) shall be determined net of any amounts actually recovered by the Indemnified Parties under the Representation and Warranty Insurance Policy with respect to such Losses (which amounts actually recovered by the Indemnified Parties shall be calculated, in each case, net of any reasonable out-of-pocket costs and any Taxes incurred in connection with such recovery). In any case where a Purchaser Indemnitee actually recovers under the Representation and Warranty Insurance Policy any amount in respect of a matter for which such Indemnified Party was previously indemnified hereunder, such Indemnified Party shall promptly pay over to the Responsible Party a refund equal to the amount so recovered (after deducting therefrom the amount of the reasonable out-of-pocket costs and expenses and any Taxes incurred in connection with such recovery), if and solely to the extent that such amount of recovery would have reduced the amount to which the Indemnified Party would have been entitled pursuant to the first sentence of this Section 7.4(e), but not in excess of the aggregate amount previously paid to the Indemnified Parties hereunder in respect of such matter; provided that for the avoidance of doubt, Purchaser shall not be required to repay to Seller any amounts recovered under the Representation and Warranty Insurance Policy to the extent such repayment would, after taking into account the deductible and other limitations under the Representation and Warranty Insurance Policy, have the effect of reducing the amount of indemnifiable Losses actually recovered by Purchaser with respect to such claim below the amount of indemnified Losses to which Purchaser would otherwise be entitled to recover from Seller pursuant to this Article VII, but for this Section 7.4(e). Purchaser covenants and agrees that the Representation and Warranty Insurance Policy will expressly exclude any right of subrogation against the Seller Group (other than with respect to Fraud).
(f) The Indemnified Parties shall be entitled to recover for a Loss only once under Article VII even if a claim or claims for indemnification in respect of such Loss has been made as a result of a breach of more than one representation, warranty, covenant or agreement contained in this Agreement.
(g) The Indemnified Parties shall not be entitled to recover any Loss to the extent such Loss was included in or otherwise expressly taken into account in the determination of the Aggregate Purchase Price.
(h) The rights to indemnification of the Indemnified Parties under this Article VII shall not be affected or deemed waived by reason of any investigation made by or on behalf of any party hereto (including by any of such party’s advisors or representatives) or by reason of the fact that such party or any of such advisors or representatives knew or should have known that any representation or warranty is, was or might be inaccurate.
(i) For purposes of determining the breach or inaccuracy of any representation or warranty of the Company set forth in Article III or the Seller set forth in Article IV and in calculating the amount of any Losses attributable thereto, any “materiality,” “Material Adverse Effect,” or similar qualifications in such representations and warranties shall be disregarded, except that the foregoing shall not apply to (i) the use of the term “Material Contract” in any representation or warranty or (ii) any representation or warranty set forth in Section 3.4(a) or Section 3.6(a).
(j) The Purchaser Indemnitees shall only be entitled to recover under this Article VII for any breach of any representations and warranties regarding Losses for Taxes with respect to taxable periods, or portions thereof, that end on or before the Closing Date, except to the extent such Losses arise from or are attributable to a breach of the representations or warranties contained in Sections 3.15(e), 3.15(k) or 3.15(l).
Exclusions and Limitations of Liability TO THE MAXIMUM EXTENT PERMITTED UNDER APPLICABLE LAW, (a) NONE OF THE 8x8 PARTIES SHALL BE LIABLE UNDER THE AGREEMENT FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL, PUNITIVE, EXEMPLARY, OR COVER DAMAGES; LOSS OF PROFITS, REVENUES, OR GOODWILL; OR LOSS OR INTERRUPTION OF BUSINESS, WHETHER FROM BREACH OR REPUDIATION OF CONTRACT, BREACH OF WARRANTY, NEGLIGENCE, TORT, STRICT LIABILITY, OR OTHERWISE AND (b) THE MAXIMUM LIABILITY OF THE 8x8 PARTIES UNDER THE AGREEMENT, WHETHER ARISING FROM A THEORY OR CLAIM OF BREACH OR REPUDIATION OF CONTRACT, BREACH OF WARRANTY, NEGLIGENCE, TORT, STATUTORY DUTY, OR OTHERWISE, SHALL IN NO CASE EXCEED THE TOTAL AMOUNT OF SERVICE FEES PAYABLE UNDER THE AGREEMENT FOR THE TWELVE- (12-) MONTH PERIOD PRECEDING THE FIRST INCIDENT OUT OF WHICH THE LIABILITY AROSE. THE FOREGOING EXCLUSION AND LIMITATION SHALL APPLY REGARDLESS OF WHETHER EITHER PARTY WAS ADVISED OF THE POSSIBILITY OF SUCH DAMAGES OR THE FAILURE OF THE ESSENTIAL PURPOSE OF ANY LIMITED REMEDY, AND ON A CUMULATIVE (RATHER THAN PER-INCIDENT) BASIS. CUSTOMER ACKNOWLEDGES AND AGREES THAT THE PRICING AND OTHER TERMS UNDER THE AGREEMENT ARE BASED ON THE FOREGOING EXCLUSION AND LIMITATION.
Indemnification and Limitation of Liability (a) In the absence of willful misfeasance, bad faith, gross negligence or reckless disregard of obligations or duties hereunder on the part of FSSC and its trustees, officers, employees, agents and representatives, the Funds agree to indemnify FSSC and its trustees, officers, employees, agents and representatives against any and all claims, demands, liabilities and reasonable expenses (including attorneys’ fees), related to or otherwise connected with (i) any breach by the Funds of any provision of this Agreement; or (ii) any action by a Fund’s Shareholder against FSSC.
(b) FSSC shall not be liable for any error of judgment or mistake of law or for any loss suffered by any Fund in connection with the matters to which this Agreement relates, except a loss resulting from willful misfeasance, bad faith or gross negligence on its part in the performance of its duties or from reckless disregard by it of its obligations and duties under this Agreement. In no event shall FSSC be liable for indirect or consequential damages.
(c) Any person, even though also an officer, trustee, partner, employee or agent of FSSC, who may be or become an officer, employee or agent of any Fund or a member of a Fund's Board, shall be deemed, when rendering services to such Fund or acting on any business of such Fund (other than services or business in connection with the duties of FSSC hereunder) to be rendering such services to or acting solely for such Fund and not as an officer, trustee, partner, employee or agent or one under the control or direction of FSSC even though paid by FSSC.
(d) FSSC is expressly put on notice of the limitation of liability as set forth in the Declaration of Trust of each Fund that is a Massachusetts business trust and agrees that the obligations assumed by each such Fund pursuant to this Agreement shall be limited in any case to such Fund and its assets and that FSSC shall not seek satisfaction of any such obligations from the Shareholders of such Fund, the Trustees, Officers, Employees or Agents of such Fund, or any of them.
(e) The provisions of this Section shall survive the termination of this Agreement.
Exclusion and Limitation of Liability 10.1 SUPPLIER DOES NOT EXCLUDE OR LIMIT ITS LIABILITY (IF ANY) TO BUYER FOR ANY MATTER FOR WHICH IT WOULD BE ILLEGAL FOR SUPPLIER TO EXCLUDE OR LIMIT OR TO ATTEMPT TO EXCLUDE OR LIMIT ITS LIABILITY.
10.2 OTHER THAN ANY LIABILITY OF SUPPLIER ARISING UNDER CLAUSE 10.1, WHICH SHALL NOT BE LIMITED, AND WITHOUT PREJUDICE TO THE OTHER PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY), SUPPLIER'S AGGREGATE LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) UNDER EACH CONTRACT WILL BE LIMITED TO AN AMOUNT EQUAL TO THE GREATER OF 115% OF THE AMOUNT PAID BY BUYER TO SUPPLIER UNDER THAT CONTRACT OR $10,000.00.
10.3 EXCEPT AS PROVIDED IN CLAUSE 10.1, SUPPLIER WILL BE UNDER NO LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) TO BUYER WHATSOEVER IN RESPECT OF
10.3.1 ANY CLAIM ARISING OUT OF AN EVENTWHICH IS CAUSED, OR CONTRIBUTED TO, BY THE GOODS AND SUCH EVENT OCCURS AFTER THE COMMENCEMENT OF THE LAUNCH PROCEDURE OF THE VEHICLE CARRYING SUCH GOODS INTO SPACE;
10.3.2 PURE ECONOMIC LOSS, LOSS OF PROFITS, LOSS OF BUSINESS, LOSS OF REVENUE, LOSS OF CONTRACTS, LOSS OF GOODWILL, LOSS OF ANTICIPATED EARNINGS OR SAVINGS (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.3 LOSS OF USE OR VALUE OR DAMAGE OF ANY DATA OR EQUIPMENT (INCLUDING SOFTWARE), WASTED MANAGEMENT, OPERATION OR OTHER TIME (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.4 ANY SPECIAL, INDIRECT, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL LOSS, IN EACH CASE HOWSOEVER CAUSED ARISING OUT OF OR IN CONNECTION WITH:
10.3.5 ANY OF THE WORKS, OR THE MANUFACTURE OR SALE OR SUPPLY, OR FAILURE OR DELAY IN SUPPLY, OF THE WORKS BY SUPPLIER OR ON THE PART OF SUPPLIER’S EMPLOYEES, AGENTS OR SUBCONTRACTORS;
10.3.6 ANY BREACH BY SUPPLIER OF ANY OF THE EXPRESS OR IMPLIED TERMS OF THE CONTRACT;
10.3.7 ANY USE MADE OR RESALE BY BUYER OF ANY OF THE WORKS, OR OF ANY PRODUCT INCORPORATING ANY OF THE WORKS; OR
10.3.8 ANY STATEMENT MADE OR NOT MADE, OR ADVICE GIVEN OR NOT GIVEN, BY OR ON BEHALF OF SUPPLIER.
10.4 EXCEPT AS EXPRESSLY SET OUT IN THE CONTRACT, SUPPLIER HEREBY EXCLUDES TO THE FULLEST EXTENT PERMISSIBLE IN LAW, ALL CONDITIONS, WARRANTIES AND STIPULATIONS, EXPRESS (OTHER THAN THOSE SET OUT IN THE CONTRACT) OR IMPLIED, STATUTORY, CUSTOMARY OR OTHERWISE WHICH, BUT FOR SUCH EXCLUSION, WOULD OR MIGHT SUBSIST IN FAVOR OF BUYER, INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
10.5 EACH OF SUPPLIER’S EMPLOYEES, AGENTS AND SUBCONTRACTORS MAY RELY UPON AND ENFORCE THE EXCLUSIONS AND RESTRICTIONS OF LIABILITY IN THE CONTRACT IN THAT PERSON’S OWN NAME AND FOR THAT PERSON’S OWN BENEFIT, AS IF THE WORDS “ITS EMPLOYEES, AGENTS AND SUBCONTRACTORS” FOLLOWED THE WORD SUPPLIER WHEREVER IT APPEARS IN THOSE CLAUSES SAVE FOR EACH REFERENCE IN CLAUSE10.3.5.
10.6 BUYER ACKNOWLEDGES THAT THE ABOVE PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY) ARE REASONABLE AND REFLECTED IN THE PRICE WHICH WOULD BE HIGHER WITHOUT THOSE PROVISIONS, AND BUYER WILL ACCEPT SUCH RISK AND/OR INSURE ACCORDINGLY.
10.7 BUYER IS SOLELY RESPONSIBLE AND LIABLE FOR THE PROPER LEGAL DISPOSAL OF ALL MATERIALS PURCHASED FROM SUPPLIER AT THE END-OF- LIFE CYCLE OF SUCH MATERIALS.
Limitations on Damages Neither Party shall be liable for any consequential, special or indirect losses or damages suffered by the other Party, whether or not the likelihood of such losses or damages was known by the Party.
Limitations on Liability The Owner Trustee will not be liable under the Transaction Documents, including for the following actions, except (a) for its own willful misconduct, bad faith or negligence (except for errors in judgment) or (b) if a representation or warranty in Section 6.6 is not true and correct as of the Closing Date:
(i) the Owner Trustee will not be liable for any action taken or not taken by it (A) according to the instructions of the Noteholders of a majority of the Note Balance of the Controlling Class, the Indenture Trustee, the Depositor, the holder of the Residual Interest, the Administrator or the Servicer or (B) in good faith which it believes to be authorized or within its rights and powers under this Agreement so long as the action taken or not taken does not amount to negligence;
(ii) the Owner Trustee will not be liable for indebtedness evidenced by or created under the Transaction Documents, including the principal of and interest on the Notes or amounts distributable to the holder of the Residual Interest;
(iii) the Owner Trustee will not be liable for (A) the validity or sufficiency of this Agreement, (B) the due execution of this Agreement by the Depositor, (C) the form, genuineness, sufficiency, value or validity of the Trust Property, (D) the validity or sufficiency of the other Transaction Documents, the Notes or related documents, (E) the legality, validity and enforceability of a Receivable, (F) the perfection and priority of a security interest created by a Receivable in a Financed Vehicle or the maintenance of any perfection and priority, (G) the sufficiency of the Trust Property or the ability of the Trust Property to generate the amounts necessary to make payments to the Noteholders under the Indenture or distributions to the holder of the Residual Interest under this Agreement or (H) the accuracy of a representation or warranty made under a Transaction Document (other than the representations and warranties made by the Owner Trustee in Section 6.6);
(iv) the Owner Trustee will not be liable for the default or misconduct of the Servicer, the Administrator, the Depositor, the holder of the Residual Interest or the Indenture Trustee under the Transaction Documents or for any action taken by the Indenture Trustee, the Administrator or the Servicer in the name of the Owner Trustee;
(v) the Owner Trustee will not be responsible or liable for special, punitive, indirect or consequential damages (including lost profit), even if the Owner Trustee has been advised of the likelihood of the loss or damage and regardless of the form of action; or
(vi) the Owner Trustee will not be responsible or liable for a failure or delay in the performance of its obligations under this Agreement from or caused by, directly or indirectly, forces beyond its control, including strikes, work stoppages, acts of war, terrorism, civil or military disturbances, nuclear catastrophes, fires, floods, earthquakes, storms, hurricanes or other natural catastrophes and interruptions, loss or failures of mechanical, electronic or communication systems, pandemics or epidemics; the Owner Trustee will use reasonable efforts consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.
