Possession and Occupancy The Seller will deliver possession and occupancy of the Property to the Buyer at Closing. The Seller shall provide access to all locks, including keys, remote controls, and any security/access codes, necessary to operate all locks, mailboxes, and security systems.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
USE AND OCCUPANCY Tenant shall use and occupy the Demised Premises for the commercial purpose of ____________________________________________________________ [Description of commercial purpose] and related activities. The Demised Premises shall be used for no other purpose without the advance written consent of Landlord. Tenant shall operate the Demised Premises in a clean and dignified manner and in compliance with all applicable laws, regulations, rules, and ordinances. Janitorial Services (Check one) ☐ Tenant shall provide its own janitorial services. ☐ As agreed by both parties, Landlord shall provide janitorial services and shared costs will be included in the Operating Cost. Tenant shall use the Demised Premises for no unlawful purpose or act; shall commit or permit no waste or damage to the Demised Premises; shall, at Tenant’s expense, comply with and obey all applicable laws, regulations, or orders of any governmental authority or agency; shall not do or permit anything to be done in or about the Demised Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Real Property; and shall comply with all the rules and requirements promulgated by Landlord with respect to the Real Property, as the same may be amended from time to time. Tenant agrees as follows: (Check all that apply)
☐ I. All loading and unloading, delivery and shipping of goods shall be conducted in such areas and through the entrances designated by Landlord.
☐ II. No window coverings, such as curtains, blinds or shades, shall be placed on the windows of Demised Premises unless approved by Landlord.
☐ III. No smoking in the Demised Premises or within __________ feet or any doorway.
☐ IV. All garbage and refuse shall be kept in the size and kind of container, and in a location approved by Landlord. Tenant shall not burn any trash or garbage in or about the Real Property.
☐ V. No aerial, loudspeaker, satellite dish, sound amplifier, equipment, displays, or advertising shall be erected on the roof or exterior walls of the Demised Premises, or on other areas of the Real Property without the prior written consent of Landlord.
☐ VI. No loudspeaker, television, phonograph, juke-box, radio, or other device shall be used in a manner so as to be heard other than by persons who are within the Demised Premises without the prior written consent of Landlord.
☐ VII. No activity will take place on the Demised Premises or common areas which shall cause any odor which can be smelled other than by persons who are within the Demised Premises.
☐ VIII. Tenant shall keep the Demised Premises at a temperature sufficiently high to prevent freezing of water in pipes and fixtures.
☐ IX. Tenant shall not permit or place any obstructions or merchandise in any common areas, including but not limited to, corridors, all sidewalks in front of, on the side of, or in the back of the Demised Premises.
☐ X. The plumbing facilities in the Demised Premises shall not be used for any purpose other than that for which they are constructed, and no foreign substance of any kind shall be thrown therein, and the expense of any breakage, stoppage, or damage resulting from a violation of this provision shall be borne by Tenant. Tenant shall be responsible for the proper and lawful disposal of all cooking grease used within the Demised Premises.
☐ XI. Tenant shall keep all windows, window xxxxx, window frames and exterior signs of the Demised Premises clean.
☐ XII. No merchandise shall be stored in the Demised Premises except that which Tenant is selling in the normal course of business in, at, or from the Demised Premises.
☐ XIII. No auctions or tent sales shall be held within the Demised Premises or on or within any portion of the Real Property, except with the prior written consent of Landlord.
☐ XIV. Landlord shall have the right to prohibit the continued use by Tenant of any unethical or unfair method of business operation, advertising or interior display if, in Landlord’s opinion, the continued use thereof would impair the reputation of the Real Property as a first class facility or is otherwise out of harmony with the general character thereof, and upon notice from Landlord shall forthwith refrain from or discontinue such activities.
☐ XV. Tenant shall keep the Demised Premises (including without limitation, exterior and interior portions of all windows, doors and all other glass) in a neat, clean and sanitary condition, free of all insects, rodents, vermin and pests of every type and kind.
☐ XVI. Tenant shall not use the Demised Premises for any purpose or business which is noxious or unreasonably offensive because of the emission of noise, smoke, dust or odors.
☐ XVII. Tenant shall keep the entry ways and sidewalk/walkway in front of the Demised Premise clear of all debris, trash and litter, and shall keep the same swept, maintained and snow and ice removed therefrom.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Landlord’s Default and Tenant’s Remedies In the event Landlord fails to perform any of its obligations under this Lease, Landlord shall nevertheless not be in default under the terms of this Lease until such time as Tenant shall have first given Landlord written notice specifying the nature of such failure to perform its obligations, and then only after Landlord shall have had a reasonable period of time following its receipt of such notice within which to perform such obligations. In the event of Landlord’s default as above set forth, then, and only then, Tenant shall have the following remedies only:
A. Tenant may then proceed in equity or at law to compel Landlord to perform its obligations and/or to recover damages proximately caused by such failure to perform (except as and to the extent Tenant has waived its right to damages as provided in this Lease).
B. Tenant, at its option, may then cure any default of Landlord at Landlord’s cost. If, pursuant to this Subarticle, Tenant reasonably pays any sum to any third party or does any act that requires the payment of any sum to any third part at any time by reason of Landlord’s default, the sum paid by, Tenant shall be immediately due from Landlord to Tenant at the time Tenant supplies Landlord with an invoice therefor (provided such invoice sets forth and is accompanied by a written statement of Tenant setting forth in reasonable detail the amount paid, the party to whom it was paid, the date it was paid, and the reasons giving rise to such payment), together with interest at twelve percent per annum from the date of such invoice until Tenant is reimbursed by Landlord. Tenant may not offset such sums against any installment of rent due Landlord under the terms of this Lease.
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant of this Tenant Work Letter or the Lease has occurred at any time on or before the Substantial Completion of the Premises and remains after the expiration of applicable notice and cure periods, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to cause the Contractor to suspend the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 4.2 above), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to a default by Tenant as described in Section 19.1 of the Lease or under this Tenant Work Letter, in addition to any other remedies available to Landlord under the Lease, at law and/or in equity, Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) business days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.
Lessee as Prior Owner/Occupant The warranties made by Lessor in Paragraph 2 shall be of no force or effect if immediately prior to the Start Date Lessee was the owner or occupant of the Premises. In such event, Lessee shall be responsible for any necessary corrective work.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
POSSESSION AND OCCUPATION 3.1 The CONTRACTOR, its agents, servants and subcontractors shall at all times until the Works have been completed and the OWNER has signed and handed to the CONTRACTOR the final completion form, be entitled to enter and be present on the property for construction purposes. The CONTRACTOR shall further be entitled to enter into and be present on the property for purposes of completing minor works and snags listed on the snag list.
3.2 At no time whatsoever shall the OWNER be entitled to make claim, attach or in any way claim possession or retention of any of the CONTRACTOR's tools, equipment or building material and by signature hereof the OWNER waives all or any right which he may have acquired in this regard.
3.3 The OWNER shall be obliged to take occupation and possession of the Works at a date agreed upon between the parties but not later than 14 (fourteen) days after the handover date and it shall be incumbent on the OWNER to monitor progress of the Works in order to enable him to make whatever arrangements which may be necessary or required by him to:
3.3.1 take possession and occupation of the Works;
3.3.2 make payment of all or any amounts which may then still be due by him to the CONTRACTOR.
3.4 Should the OWNER fail to take occupation and possession of the Works as provided in clause 3.3 OR on such other date as may be agreed between the parties in writing –
3.4.1 it shall irrevocably be deemed for all purposes hereunder, that the OWNER has effectively and fully taken occupation and possession of the property and Works as set out in clause 3.3 and that all items on the snag list have been completed and accepted by the OWNER;
3.4.2 the CONTRACTOR shall not be responsible for any damages to the property after the deemed occupation date and the OWNER shall at his own cost provide security for the property against any vandalism and/or theft and/or any other damages thereto.
3.5 The CONTRACTOR shall, within 14 (fourteen) days from the commencement date as defined in clause 1.1.12, inform the OWNER of the estimated occupation date in writing. It is recorded that -
3.5.1 subject to the bond being registered and/or required proof regarding payment arrangements being submitted by the estimated building commencement date, the date on which the OWNER shall be able to occupy the property is estimated to be approximately 150 (one hundred and fifty) days after the commencement date, subject to the provisions of clause 5.6.
3.5.2 should the CONTRACTOR be unable to meet the estimated occupation date defined in clause 1.1.12 and referred to in clause 3.5.1, he shall be obliged to inform the OWNER in writing thereof at least 30 (thirty) days in advance.
