Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Determination of Agreement 29. (1) In any of the following events namely if —
Determination of One-Month LIBOR Pursuant to the terms of the Global Agency Agreement, the Global Agent shall calculate the Class Coupons for the applicable Classes of Notes (including MAC Notes on which the Exchange Administrator has directed the Global Agent to make payments) for each Accrual Period (after the first Accrual Period) on the applicable LIBOR Adjustment Date. “One-Month LIBOR” will be determined by using the “Interest Settlement Rate” for U.S. dollar deposits with a maturity of one month set by ICE Benchmark Administration Limited (“ICE”) as of 11:00 a.m. (London time) on the LIBOR Adjustment Date (the “ICE Method”). ICE’s Interest Settlement Rates are currently displayed on Bloomberg L.P.’s page “BBAM.” That page, or any other page that may replace page BBAM on that service or any other service that ICE nominates as the information vendor to display the ICE’s Interest Settlement Rates for deposits in U.S. dollars, is a “Designated Page.” ICE’s Interest Settlement Rates currently are rounded to five decimal places. If ICE’s Interest Settlement Rate does not appear on the Designated Page as of 11:00 a.m. (London time) on a LIBOR Adjustment Date, or if the Designated Page is not then available, One-Month LIBOR for that date will be the most recently published Interest Settlement Rate. If ICE no longer sets an Interest Settlement Rate, Freddie Mac will designate an alternative index that has performed, or that Freddie Mac (or its agent) expects to perform, in a manner substantially similar to ICE’s Interest Settlement Rate.
CERTIFICATION OF INDEPENDENT PRICE DETERMINATION By submission of this bid, the Bidder certifies, and in the case of a joint bid each party thereto certifies as to its own organization, that in connection with this procurement:
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
Performance Appraisal The Executive’s performance may be evaluated by the Board of Directors or the Committee from time to time. The Executive shall be entitled to such additional remuneration, including but not limited to annual bonuses based on performance, as the Board of Directors or the Committee may, in its discretion, determine from time to time.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Penalty Determination H&SC section 39619.7 requires CARB to provide information on the basis for the penalties it seeks. This Agreement includes this information, which is also summarized here. The provision of law the penalty is being assessed under and why that provision is most appropriate for that violation. The penalty provision being applied in this case is H&SC section 42402 et seq. because IIT sold, supplied, offered for sale, consumer products for commerce in California in violation of the Consumer Products Regulations (17 CCR section 94507 et seq.). The penalty provisions of H&SC section 42402 et seq. apply to violations of the Consumer Products Regulations because the regulations were adopted under authority of H&SC section 41712, which is in Part 4 of Division 26. The manner in which the penalty amount was determined, including aggravating and mitigating factors and per unit or per vehicle basis for the penalty. H&SC section 42402 et seq. provides strict liability penalties of up to $10,000 per day for violations of the Consumer Product Regulations with each day being a separate violation. In cases like this, involving unintentional violations of the Consumer Products Regulations where the violator cooperates with the investigation, CARB has obtained penalties for selling uncertified charcoal lighter material in California. In this case, the total penalty is $7,500 for selling uncertified charcoal lighter material in California. The penalty in this case was reduced because this was a strict liability first-time violation and IIT made diligent efforts to cooperate with the investigation. To come into compliance, IIT no longer offers Safegel BBQ & Fireplace Lighting Gel Fire Starter for commerce in California. Final penalties were determined based on the unique circumstances of this matter, considered together with the need to remove any economic benefit from noncompliance, the goal of deterring future violations and obtaining swift compliance, the consideration of past penalties in similar negotiated cases, and the potential cost and risk associated with litigating these particular violations. The penalty reflects violations extending over a number of days resulting in quantifiable harm to the environment considered together with the complete circumstances of this case. Penalties in future cases might be smaller or larger on a per ton basis. The final penalty in this case was based in part on confidential financial information or confidential business information provided by IIT that is not retained by CARB in the ordinary course of business. The penalty in this case was also based on confidential settlement communications between CARB and IIT that CARB does not retain in the ordinary course of business. The penalty also reflects CARB’s assessment of the relative strength of its case against IIT, the desire to avoid the uncertainty, burden and expense of litigation, obtain swift compliance with the law and remove any unfair advantage that IIT may have secured from its actions. Is the penalty being assessed under a provision of law that prohibits the emission of pollution at a specified level, and, if so a quantification of excess emissions, if it is practicable to do so. The Consumer Product Regulations do not prohibit emissions above a specified level, but they do limit the concentration of VOCs in regulated products. In this case, a quantification of the excess emissions attributable to the violations was not practicable.
