Specific Remedies (a) During any period other than a Cash Dominion Trigger Period and subject to the terms of the Credit Agreement, the Administrative Agent hereby authorizes each Grantor to collect such Grantor’s Accounts in the Ordinary Course of Business.
(b) During a Cash Dominion Trigger Period:
(i) upon the request of the Administrative Agent, each Grantor shall notify (such notice to be in form and substance satisfactory to the Administrative Agent) its Account Debtors and parties to the Material Contracts subject to a Security Interest that such Accounts and the Material Contracts have been assigned to the Administrative Agent, for the ratable benefit of the Secured Parties;
(ii) upon the request of the Administrative Agent, each Grantor shall forward to the Administrative Agent, on the last Business Day of each week, deposit slips related to all cash, money, checks or any other similar items of payment received by the Grantor during such week, and copies of such checks or any other similar items of payment, together with a statement showing the application of all payments on the Collateral during such week and a collection report with regard thereto, in form and substance satisfactory to the Administrative Agent;
(iii) the Administrative Agent may deliver such notices and instructions in accordance with control agreements covering Deposit Accounts (other than Excluded Accounts) and/or Securities Accounts. In addition, whenever any Grantor shall receive any cash, money, checks or any other similar items of payment relating to any Collateral (including any Proceeds of any Collateral), subject to the terms of any Permitted Liens, such Grantor agrees that it will, within one (1) Business Day of such receipt, deposit all such items of payment into the Dominion Account, and until such Grantor shall deposit such cash, money, checks or any other similar items of payment in the Dominion Account, such Grantor shall hold such cash, money, checks or any other similar items of payment in trust for the Secured Parties and as property of the Secured Parties, separate from the other funds of such Grantor, and the Administrative Agent shall have the right to transfer or direct the transfer of the balance of each Deposit Account (other than an Excluded Deposit Account) to the Dominion Account. All such Collateral and Proceeds of Collateral received by the Administrative Agent hereunder shall be held by the Administrative Agent in the Dominion Account as collateral security for all the Secured Obligations and shall not constitute payment thereof until applied as provided in Section 5.4;
(c) After the occurrence and during the continuance of an Event of Default:
(i) the Administrative Agent shall have the right to receive any and all cash dividends, payments or distributions made in respect of any Investment Property, any Partnership/LLC Interests or any other Proceeds paid in respect of any Investment Property or any Partnership/LLC Interests, and any or all of any Investment Property that is included as Collateral or any Partnership/LLC Interests that are Pledged Capital Stock may, at the option of the Administrative Agent and the Secured Parties, be registered in the name of the Administrative Agent or its nominee, and the Administrative Agent or its nominee may thereafter exercise (A) all voting, corporate and other rights pertaining to such Investment Property, or such Partnership/LLC Interests at any meeting of shareholders, partners or members of the relevant Issuers or otherwise and (B) any and all rights of conversion, exchange and subscription and any other rights, privileges or options pertaining to such Investment Property or such Partnership/LLC Interests as if it were the absolute owner thereof (including, without limitation, the right to exchange at its discretion any and all Investment Property or any and all Partnership/LLC Interests issued upon the merger, consolidation, reorganization, recapitalization or other fundamental change in the corporate, partnership or limited liability company structure of any Issuer that is a Grantor (other than Imation) or a Pledged Foreign Subsidiary or upon the exercise by any Grantor or the Administrative Agent of any right, privilege or option pertaining to such Investment Property or such Partnership/LLC Interests, and in connection therewith, the right to deposit and deliver any and all of such Investment Property or any and all of such Partnership/LLC Interests with any committee, depositary, transfer agent, registrar or other designated agency upon such terms and conditions as the Administrative Agent may determine), all without liability except to account for property actually received by it; but the Administrative Agent shall have no duty to any Grantor to exercise any such right, privilege or option and the Administrative Agent and the other Secured Parties shall not be responsible for any failure to do so or delay in so doing. In furtherance thereof, each Grantor hereby authorizes and instructs each Issuer (i) that is a Grantor (other than Imation) or a Pledged Foreign Subsidiary with respect to any Collateral consisting of Investment Property and Partnership/LLC Interests of such Issuer to comply with any instruction received by it from the Administrative Agent in writing that (A) states that an Event of Default has occurred and is continuing and (B) is otherwise in accordance with the terms of this Agreement, without any other or further instructions from such Grantor, and each Grantor agrees that each Issuer shall be fully protected in so complying following receipt of such notice and prior to notice that such Event of Default is no longer continuing, and (ii) except as otherwise expressly permitted hereby and solely during a Cash Dominion Trigger Period, to pay any cash dividends, distributions or other payments with respect to any Investment Property, or Partnership/LLC Interests issued by such Issuer directly to the Dominion Account or such other Controlled Depositary as the Administrative Agent may direct; and
(ii) the Administrative Agent shall be entitled to (but shall not be required to): (A) proceed to perform any and all obligations of the applicable Grantor under any Material Contract and exercise all rights of such Grantor thereunder as fully as such Grantor itself could, (B) do all other acts which the Administrative Agent may deem necessary or proper to protect its Security Interest granted hereunder, provided such acts are not inconsistent with or in violation of the terms of any of the Credit Agreement, of the other Loan Documents or applicable Law, and (C) sell, assign or otherwise transfer any Material Contract in accordance with the Credit Agreement, the other Loan Documents and applicable Law, subject, however, to the prior approval of each other party to such Material Contract, to the extent required under the Material Contract.
(iii) The Administrative Agent is hereby granted an irrevocable, non-exclusive license or other right to use, license or sub-license (without payment of royalty or other compensation to any Person) of any or all Intellectual Property of each Grantor, computer hardware and software, trade secrets, brochures, customer lists, promotional and advertising materials, labels, packaging materials and other Property, in advertising for sale, marketing, selling, collecting, completing manufacture of, or otherwise exercising any rights or remedies with respect to, any Collateral; provided that the Administrative Agent shall not be entitled to exercise its rights under any such license, sub-license or right to use until such time as the Administrative Agent shall have received consent or direction from the Required Lenders pursuant to Section 8.02(d) of the Credit Agreement.
(d) Unless an Event of Default shall have occurred and be continuing and the Administrative Agent shall have given notice to the relevant Grantor of the Administrative Agent’s intent to exercise its corresponding rights pursuant to Section 5.2(b), each Grantor shall be permitted to receive all cash dividends, payments or other distributions made in respect of any Investment Property and any Partnership/LLC Interests, in each case paid in the Ordinary Course of Business to the extent permitted in the Credit Agreement, and to exercise all voting and other corporate, company and partnership rights with respect to any Investment Property and Partnership/LLC Interests; provided that, no vote shall be cast or other corporate, company and partnership right exercised or other action taken which, in the Administrative Agent’s reasonable judgment, would impair the Collateral in any material respect or which would result in a Default or Event of Default under any provision of the Credit Agreement, this Agreement or any other Loan Document.
CUSTOMER REMEDIES 5.1. If the Supplier (a) fails to deliver the Goods and/or the Goods do not comply with any of the undertakings or warranties set out in clause 2 and/or (b) fails to deliver and/or perform the Services in accordance with any of the warranties or undertakings contained in clause 4 and/or by the applicable date(s), the Customer shall, without limiting or affecting other rights or remedies available to it, have one or more of the following rights to:
5.1.1. terminate the Agreement with immediate effect by giving written notice to the Supplier;
5.1.2. reject the Goods (in whole or in part) whether or not title has passed and to return them to the Supplier at the Supplier’s own risk and expense;
5.1.3. require the Supplier to repair or replace the rejected Goods, or to provide a full refund of the price of the rejected Goods;
5.1.4. require Supplier to re-perform, rectify or replace the affected Services and/or Deliverables;
5.1.5. refuse to accept any subsequent performance of the Services and/or delivery of the Goods which the Supplier attempts to make;
5.1.6. recover from the Supplier any costs incurred by the Customer in obtaining substitute goods and/or services from a third party;
5.1.7. require a refund from the Supplier of sums paid in advance for Services that the Supplier has not provided and/or Goods that it has not delivered; and
5.1.8. claim damages for any additional costs, loss or expenses incurred by the Customer which are in any way attributable to the Supplier’s breach.
5.2. Notwithstanding any other rights or remedies available to Customer if the Goods are not delivered by the applicable date, the Customer may, at its option, claim or deduct 3% of the price of the Goods for each week’s delay in delivery, up to a maximum of 15% of the total price of the Goods. In the event such delay continues for six (6) weeks or more, Customer may terminate the Agreement with immediate effect upon given Supplier written notice.
5.3. These Terms shall extend to any substituted or remedial services and/or repaired or replacement goods supplied by the Supplier.
5.4. The Customer’s rights under the Agreement are in addition to its rights and remedies implied by statute and common law.
Performance Default and Remedies Subsection B. DEFAULT AND REMEDIES, second paragraph of the Contract is modified as follows (underlined language is added and stricken language is deleted): “Written notice of default and a reasonable 30-day opportunity to cure must be issued by the party claiming default.”
Availability of Equitable Remedies Since a breach of the provisions of this Agreement could not adequately be compensated by money damages, any party shall be entitled, either before or after the Closing, in addition to any other right or remedy available to it, to an injunction restraining such breach or a threatened breach and to specific performance of any such provision of this Agreement, and in either case no bond or other security shall be required in connection therewith, and the parties hereby consent to the issuance of such an injunction and to the ordering of specific performance.
Acceleration; Remedies Upon the occurrence and during the continuance of an Event of Default, then, and in any such event, (a) if such event is a Bankruptcy Event, automatically the Commitments shall immediately terminate and the Loans (with accrued interest thereon), and all other amounts under the Credit Documents (including, without limitation, the maximum amount of all contingent liabilities under Letters of Credit) shall immediately become due and payable, and (b) if such event is any other Event of Default, any or all of the following actions may be taken: (i) with the written consent of the Required Lenders, the Administrative Agent may, or upon the written request of the Required Lenders, the Administrative Agent shall, declare the Commitments to be terminated forthwith, whereupon the Commitments shall immediately terminate; (ii) the Administrative Agent may, or upon the written request of the Required Lenders, the Administrative Agent shall, declare the Loans (with accrued interest thereon) and all other amounts owing under this Agreement and the Notes to be due and payable forthwith and direct the Borrower to pay to the Administrative Agent cash collateral as security for the LOC Obligations for subsequent drawings under then outstanding Letters of Credit an amount equal to the maximum amount of which may be drawn under Letters of Credit then outstanding, whereupon the same shall immediately become due and payable; and/or (iii) with the written consent of the Required Lenders, the Administrative Agent may, or upon the written request of the Required Lenders, the Administrative Agent shall, exercise such other rights and remedies as provided under the Credit Documents and under applicable law.
City’s Remedies In addition to any other remedies the City may have upon Developer and/or Developer’s contractor for the failure to provide and maintain insurance or policy endorsements to the extent and within the time required, the City shall have the right, to order Developer to stop work, and/or withhold any payment(s), which become due until Developer and/or Developer’s contractor demonstrates compliance with the requirements.
Termination Remedies (a) If all conditions precedent to the obligations of Buyer set forth in Article VII, or of Seller set forth in Article VIII, (such Party that has satisfied its conditions precedent, the “Performing Party”) have been met and the transactions contemplated by this Agreement are not consummated on or before the Closing Date because of the failure of Buyer or Seller to perform any of its material obligations hereunder or the breach of any representation herein by Buyer or Seller (such party that has not satisfied its conditions precedent, the “Breaching Party”) and the Performing Party has performed all of its material obligations hereunder and has not breached any representation herein, then in such event, the Performing Party shall have the option to terminate this Agreement, in which case (i) if Buyer is the Breaching Party, Seller shall retain the Deposit as liquidated damages on account of Buyer’s failure to perform its obligations under this Agreement or Buyer’s breach of any representation under this Agreement, which remedy shall be the sole and exclusive remedy available to Seller for Buyer’s breaches or (ii) if Seller is the Breaching Party, then Seller shall return the Deposit to Buyer in immediately available funds within three (3) calendar days after receipt of Buyer’s notice of termination. Buyer and Seller acknowledge and agree that (i) the Seller’s actual damages upon the event of such a termination are difficult to ascertain with any certainty, (ii) that the Deposit is a reasonable estimate of such actual damages and (iii) such liquidated damages do not constitute a penalty. Additionally, if Seller is the Breaching Party, in lieu of terminating this Agreement, Buyer shall have the right of specific performance of this Agreement.
(b) If this Agreement is terminated for any reason, other than as set forth in Section 11.03(a), then Seller shall return the Deposit to Buyer in immediately available funds within three (3) calendar days after the event giving rise to such payment to Buyer. Buyer and Seller shall thereupon have the rights and obligations set forth elsewhere herein.
Lessor’s Remedies In the event Lessee is in default pursuant to the conditions set forth in Section 15.01 above, Lessor, during the continuation of such default, shall have the option of pursuing either of the following remedies:
(a) Lessor may terminate this Lease Agreement, in which event Lessee immediately shall surrender possession of the Demised Premises. All obligations of Lessee under the Lease Agreement, including Lessee’s obligation to pay rent under the Lease Agreement, shall cease upon the date of termination except for Lessee’s obligation to pay rent due and outstanding as of the date of termination.
(b) Lessor, without terminating the Lease Agreement, may require Lessee to remove all property from the Common Improvements within thirty (30) days so that Lessor may re-enter and relet the premises to minimize Lessor’s damages. In the event Lessee shall fail to remove all property within thirty (30) days after said demand, Lessor shall be entitled to remove Lessee’s property to a storage facility, and all reasonable costs of such removal and storage shall be deemed additional rent under the Lease Agreement for which Lessee is responsible for payment. Lessor may enforce all of its rights and remedies under this Lease Agreement, including the right to recover the rent as it becomes due hereunder, provided that Lessor shall have an affirmative obligation to use Lessor’s best efforts to re-let the Common Improvements and to mitigate its damages under the Lease Agreement.
(c) If this Lease Agreement is terminated as set forth, Lessor may relet the Common Improvements (or any portion thereof) for such rent and upon such terms as Lessor is able to obtain (which may be for lower or higher rent, and for a shorter or longer term), and Lessee shall be liable for all damages sustained by Lessor, including but not limited to any deficiency in Rent for the duration of the Lease Term (or for the period of time which would have remained in the Lease Term in the absence of any termination, leasing fees, attorneys’ fees, other marketing and collection costs and all expenses of placing the Common Improvements in first class rentable condition).
(d) Nothing contained herein diminishes any right Lessor may have under South Carolina law to xxx Lessee for damages in the event of any default by Lessee under this Lease Agreement, or from pursuing any other remedy available to Lessor at law or in equity.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
Company Remedies The Executive acknowledges and agrees that any breach of this Section 9 will result in immediate and irreparable harm to the Company, and that the Company cannot be reasonably or adequately compensated by damages in an action at law. In the event of a breach by the Executive of the provisions of this Section 9, the Company shall be entitled, to the extent permitted by law, immediately to cease to pay or provide the Executive or the Executive’s dependents any compensation or benefit being, or to be, paid or provided to the Executive pursuant to Section 3, Section 6 or Section 8 of this Agreement, and also to obtain immediate injunctive relief restraining the Executive from conduct in breach of the covenants contained in this Section 9. Nothing herein shall be construed as prohibiting the Company from pursuing any other remedies available to it for such breach, including the recovery of damages from the Executive.
