Equipment Failures In the event of equipment failures beyond the Administrator's control, the Administrator shall take reasonable and prompt steps to minimize service interruptions but shall have no liability with respect thereto. The Administrator shall develop and maintain a plan for recovery from equipment failures which may include contractual arrangements with appropriate parties making reasonable provision for emergency use of electronic data processing equipment to the extent appropriate equipment is available.
Payment Failure Any Credit Party (i) fails to pay any principal when due under this Agreement or (ii) fails to pay, within three Business Days of when due, any other amount due under this Agreement or any other Credit Document, including payments of interest, fees, reimbursements, and indemnifications;
Epidemic Failure “Epidemic Failure” for any particular Product shall mean a failure resulting from defects in material, workmanship, and manufacturing process, including but not limited to the use of Components with known defects. The Epidemic Failure clause shall be invoked [***]. The failure rate may be calculated [***], as determined by BUYER. Epidemic failures do not supersede the requirements of any expressed or implied warranty defined herein. In the case of an epidemic failure, SUPPLIER’s obligation is to propose an action plan to fix the failure of any affected Product within seventy-two (72) hours of discovery. SUPPLIER shall implement this action plan upon BUYER’s acceptance thereof. If the action plan is not acceptable to BUYER, BUYER can require SUPPLIER to repair or replace, at BUYER’s option, the affected Product. In addition to bearing the costs associated therewith, if requested by BUYER, SUPPLIER shall support and provide at SUPPLIER’s expense a sufficient number of units of the Product to permit the field exchange or “hot swap” of Products at customer sites. The parties agree to make all reasonable efforts to complete the repair or replacement of all affected Products within eight (8) Business Days after written notice of epidemic failure by BUYER to SUPPLIER. SUPPLIER also agrees that BUYER will be supported with accelerated shipments of replacement Product to cover BUYER’s supply requirements. If an Epidemic Failure is caused by (i) a design, including a BUYER-provided test process, as required by the Specifications or (ii) a failure by a Component required by the Specifications, (iii) misuse or damage during transit or damage by a third party at no fault of SUPPLIER, SUPPLIER shall perform the obligations in this Section 10.5 and BUYER shall pay to SUPPLIER the fees mutually agreed upon by the parties in writing. If an Epidemic Failure is caused by any other reason other than as set forth in the immediately preceding sentence, SUPPLIER shall perform the obligations set forth in this Section free of charge. Confidential treatment is being requested for portions of this document. This copy of the document filed as an exhibit omits the confidential information subject to the confidentiality request. Omissions are designated by the symbol [***]. A complete version of this document has been filed separately with the Securities and Exchange Commission.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Scheduled Outages (1) No later than five (5) Business Days prior to the dates required by the ISO for delivery of schedules for planned outages (which such ISO required delivery dates are currently January 15th, April 15th, July 15th and October 15th of each calendar year during the Facility Term), and at least sixty (60) days prior to the later of: (A) Initial Synchronization, or (B) SCE becoming Seller’s Scheduling Coordinator, Seller shall submit to SCE its schedule of proposed planned outages (“Outage Schedule”) for the subsequent twenty four-month period using the Web Client. If Seller fails to submit an Outage Schedule for any period as required under this Section 3.19, then Seller shall not be permitted to schedule or have any planned outages with respect to such period. The foregoing shall not prevent Seller from modifying its Outage Schedule in cooperation with SCE and the ISO. SCE shall provide Notice to Seller in the event that the ISO changes the ISO required delivery dates for schedules for planned outages. In addition, no later than thirty (30) days prior to October 15 of each year, Seller shall submit to SCE its estimate of its planned outages for the following year. (2) Seller shall provide the following information for each proposed planned outage: (A) Start date and time; (B) End date and time; and (C) Capacity expected to be online, in MW, during the planned outage. (3) Within twenty (20) Business Days after SCE’s receipt of an Outage Schedule, SCE shall notify Seller in writing of any reasonable request for changes to the Outage Schedule, and Seller shall, consistent with Prudent Electrical Practices and as permitted by the ISO, accommodate SCE’s requests regarding the timing of any planned outage. (4) Seller shall cooperate with SCE to arrange and coordinate all Outage Schedules with the ISO. (5) In the event a condition occurs at the Generating Facility which causes Seller to revise its planned outages, Seller shall provide Notice to SCE, using the Web Client, of such change (including an estimate of the length of such planned outage) as soon as practicable after the condition causing the change becomes known to Seller. (6) Seller shall promptly prepare and provide to SCE upon request, using the Web Client, all reports of actual or forecasted outages that SCE may reasonably require for the purpose of enabling SCE to comply with Section 761.3 of the California Public Utilities Code or any Applicable Law mandating the reporting by investor owned utilities of expected or experienced outages by electric energy generating facilities under contract to supply electric energy.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Planned Outages Seller shall schedule Planned Outages for the Project in accordance with Good Industry Practices and with the prior written consent of Buyer, which consent may not be unreasonably withheld or conditioned. The Parties acknowledge that in all circumstances, Good Industry Practices shall dictate when Planned Outages should occur. Seller shall notify Buyer of its proposed Planned Outage schedule for the Project for the following calendar year by submitting a written Planned Outage schedule no later than October 1st of each year during the Delivery Term. The Planned Outage schedule is subject to Buyer’s approval, which approval may not be unreasonably withheld or conditioned. Buyer shall promptly respond with its approval or with reasonable modifications to the Planned Outage schedule and Seller shall use its best efforts in accordance with Good Industry Practices to accommodate Xxxxx’s requested modifications. Notwithstanding the submission of the Planned Outage schedule described above, Seller shall also submit a completed Outage Notification Form to Buyer no later than fourteen (14) days prior to each Planned Outage and all appropriate outage information or requests to the CAISO in accordance with the CAISO Tariff. Seller shall contact Buyer with any requested changes to the Planned Outage schedule if Seller believes the Project must be shut down to conduct maintenance that cannot be delayed until the next scheduled Planned Outage consistent with Good Industry Practices. Seller shall not change its Planned Outage schedule without Buyer’s approval, not to be unreasonably withheld or conditioned. Seller shall use its best efforts in accordance with Good Industry Practices not to schedule Planned Outages during the months of July, August, September and October. At Buyer’s request, Seller shall use commercially reasonable efforts to reschedule Planned Outage so that it may deliver Product during CAISO declared or threatened emergency periods. Seller shall not substitute Energy from any other source for the output of the Project during a Planned Outage.
Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.
Delivery Delay The delivery of any certificate representing the Restricted Stock or other RS Property may be postponed by the Company for such period as may be required for it to comply with any applicable foreign, federal, state or provincial securities law, or any national securities exchange listing requirements and the Company is not obligated to issue or deliver any securities if, in the opinion of counsel for the Company, the issuance of such Shares shall constitute a violation by the Participant or the Company of any provisions of any applicable foreign, federal, state or provincial law or of any regulations of any governmental authority or any national securities exchange.
