Remedies of the Trustee and Securityholders on Event of Default SECTION 5.1 Event of Default Defined; Acceleration of Maturity; Waiver of Default. "Event of Default" with respect to Securities of any series wherever used herein, means each one of the following events which shall have occurred and be continuing (whatever the reason for such Event of Default and whether it shall be voluntary or involuntary or be effected by operation of law, pursuant to Article Thirteen or pursuant to any judgment, decree or order of any court or any order, rule or regulation of any administrative or governmental body):
Material Contracts; Defaults (a) Other than as disclosed in the Company Reports filed prior to the date hereof or as set forth in Company Disclosure Schedule 3.13, neither Company nor any of its Subsidiaries is a party to, bound by or subject to any agreement, contract, arrangement, commitment or understanding (whether written or oral) (i) with respect to the employment of any directors, officers, employees or consultants, (ii) which would entitle any present or former director, officer, employee or agent of Company or any of its Subsidiaries to indemnification from Company or any of its Subsidiaries, (iii) the benefits of which will be increased, or the vesting of benefits of which will be accelerated, by the occurrence of any of the transactions contemplated by this Agreement, or the value of any of the benefits of which will be calculated on the basis of any of the transactions contemplated by this Agreement, (iv) which grants any right of first refusal, right of first offer or similar right with respect to any material assets or properties of Company and or Subsidiaries; (v) which provides for payments to be made by Company or any of its Subsidiaries upon a change in control thereof; (vi) which provides for the lease of personal property having a value in excess of $25,000 individually or $100,000 in the aggregate; (vii) which relates to capital expenditures and involves future payments in excess of $10,000 individually or $50,000 in the aggregate; (viii) which relates to the disposition or acquisition of assets or any interest in any business enterprise outside the ordinary course of Company’s business; (ix) which is not terminable on sixty (60) days or less notice and involving the payment of more than $25,000 per annum; or (x) which materially restricts the conduct of any business by Company of any of its Subsidiaries (collectively, “Material Contracts”). Company has previously delivered to Buyer true, complete and correct copies of each such document.
(b) Neither Company nor any of its Subsidiaries is in default under any contract, agreement, commitment, arrangement, lease, insurance policy or other instrument to which it is a party, by which its assets, business, or operations may be bound or affected, or under which it or its assets, business, or operations receives benefits, and there has not occurred any event that, with the lapse of time or the giving of notice or both, would constitute such a default. No power of attorney or similar authorization given directly or indirectly by Company is currently outstanding.
EVENTS OF DEFAULTS AND CONSEQUENCES 9.1 Subject to the Force Majeure clause, the Promoter shall be considered under a condition of Default, in the following events:
(i) Promoter fails to provide ready to move in possession of the [Apartment/Plot] to the Allottee within the time period specified in para 7.1 or fails to complete the project within the stipulated time disclosed at the time of registration of the project with the Authority. For the purpose of this para, 'ready to move in possession' shall mean that the apartment shall be in a habitable condition which is complete in all respects including the provision of all specifications, amenities and facilities, as agreed to between the parties, and for which occupation certificate and completion certificate, as the case may be, has been issued by the competent authority;
(ii) Discontinuance of the Promoter’s business as a developer on account of suspension or revocation of his registration under the provisions of the Act or the rules or regulations made the re under.
9.2 In case of Default by Promoter under the conditions listed above, Allottee is entitled to the following:
(i) Stop making further payments to Promoter as demanded by the Promoter. If the Allottee stops making payments, the Promoter shall correct the situation by completing the construction milestones and only thereafter the Allottee be required to make the next payment without any interest; or
(ii) The Allottee shall have the option of terminating the Agreement in which case the Promoter shall be liable to refund the entire money paid by the Allottee under any head whatsoever towards the purchase of the apartment, along with interest at the rate prescribed in the Rules within forty-five days of receiving the termination notice: Provided that where an Allottee does not intend to withdraw from the project or terminate the Agreement, he shall be paid, by the promoter, interest at the rate prescribed in the Rules, for every month of delay till the handing over of the possession of the [Apartment/Plot], which shall be paid by the promoter to the allottee within forty-five days of it becoming due.
9.3 The Allottee shall be considered under a condition of Default, on the occurrence of the following events:
(i) In case the Allottee fails to make payments for consecutive demands made by the Promoter as per the Payment Plan annexed hereto, despite having been issued notice in that regard the allottee shall be liable to pay interest to the promoter on the unpaid amount at the rate prescribed in the Rules;
(ii) In case of Default by Allottee under the condition listed above continues for a period beyond consecutive months after notice from the Promoter in this regard, the Promoter may cancel the allotment of the [Apartment/Plot] in favour of the Allottee and refund the money paid to him by the allottee by deducting the booking amount and the interest liabilities and this Agreement shall thereupon stand terminated. Provided that the promoter shall intimate the allottee about such termination at least thirty days prior to such termination.
Consents Defaults (i) GOVERNMENTAL AND THIRD PARTY APPROVALS. All necessary approvals, authorizations and consents, if any be required, of any Person, including, without limitation, board approvals of the Parent and the General Partner, as applicable, and of all Governmental Authorities and courts having jurisdiction with respect to the transactions contemplated by this Agreement and the other Loan Documents shall have been obtained.
Events of Default and Their Effect 23.1 Each of the following will constitute an "Event of Default":
(a) you fail to satisfy any material provision of this Agreement and such failure continues for more than 3 Business Days after we have given you the relevant notice of non- performance;
(b) you fail to perform a material obligation under this Agreement and such failure is reasonably likely to expose us to the risk of a loss such that it is not possible for us, acting reasonably, to give you notice of non-performance;
(c) you fail to provide us with any information or notice required pursuant to this Agreement or provide false, incomplete or misleading information;
(d) you die or become of unsound mind;
(e) we consider it reasonably necessary to prevent what we reasonably consider to be or might be a violation of any Applicable Law (including but not limited to, Market Abuse, gaming the system, or Scalping);
(f) you withdraw your consent to conduct business electronically at any time by providing notice in accordance with this Agreement;
(g) you enter into liquidation or bankruptcy, whether compulsorily or voluntarily, or a procedure is commenced against you seeking or proposing liquidation or bankruptcy, or you are generally unable to pay your debts as they become due (or you admit so in writing);
(h) you become subject to an administration order or have a receiver or similar appointment or order are made or proceedings commenced in respect of any of your assets in consequence of debt;
(i) we reasonably believe you have acted in an unfair or abusive manner, for example, but not limited to, using any ultra-high speed trading; automated or mass data entry system; or Scalping with or on the Trading Platform;
(j) you make any misrepresentation or breach of warranty under this Agreement including but not limited to any misrepresentation or breach of warranty under paragraph 27.1; or
(k) we have reason to believe that any of the foregoing is likely to occur imminently or any other circumstances where we reasonably believe that it is necessary or desirable to take any action set out in paragraph 23.2.
23.2 If an Event of Default occurs, unless otherwise prescribed by Applicable Law, we may, in our absolute discretion, at any time and without prior notice, take one or more of the following steps:
(a) close out all or any of your Open Positions at current quotes;
(b) debit (or credit) your Account for amounts which are due to us (or you);
(c) close your Account, including any or all landing or trading accounts; or
(d) refuse to open new Positions, landing accounts or trading accounts for you.
23.3 In the case of an Event of Default under paragraph 23.1(f), any communications between us and you during the period before the withdrawal of your consent to do business electronically, will be valid and binding on both you and us.
23.4 In the case of an Event of Default under paragraph 23.1(j), you agree to accept the risk and liability for any resulting financial loss and any negative balances, on a Transaction, which will become immediately due and payable.
23.5 If we, in our sole discretion, believe that your Account has been involved in any fraud or crime or violation of laws or regulations, or has been accessed unlawfully, or is otherwise involved in any suspicious activity (whether victim or perpetrator or otherwise), we may suspend or freeze the Account or any privileges of the Account, may freeze or liquidate funds or Positions, or may avail ourselves of any of the remedies for an "Event of Default" in this Agreement.
23.6 Our rights and remedies under this Agreement are cumulative, and our exercise or waiver of any right or remedy will not preclude or inhibit the exercise of any additional right or remedy. Our failure to enforce or exercise any right under this Agreement will not amount to a waiver or bar to enforcement of that right.
Absence of Existing Defaults and Conflicts Neither the Company nor any of its subsidiaries is in violation of its respective charter or by-laws or in default (or with the giving of notice or lapse of time would be in default) under any existing obligation, agreement, covenant or condition contained in any indenture, loan agreement, mortgage, lease or other agreement or instrument to which any of them is a party or by which any of them is bound or to which any of the properties of any of them is subject, except such defaults that would not, individually or in the aggregate, result in a Material Adverse Effect.
Waiver of Existing Defaults Subject to Section 9.02, the Holders of a majority in principal amount of the outstanding Securities of a Series on behalf of all the Holders of the Series by notice to the Trustee may waive an existing Default on such Series and its consequences. When a Default is waived, it is cured and stops continuing, and any Event of Default arising therefrom shall be deemed to have been cured; but no such waiver shall extend to any subsequent or other Default or impair any right consequent thereon.
Waiver of Past Defaults and Events of Default Subject to Sections 6.02, 6.08 and 8.02, the Holders of a majority in aggregate principal amount of the Notes then outstanding have the right to waive any existing Default or compliance with any provision of this Indenture or the Notes. Upon any such waiver, such Default shall cease to exist, and any Event of Default arising therefrom shall be deemed to have been cured for every purpose of this Indenture; but no such waiver shall extend to any subsequent or other Default or impair any right consequent thereto.
Absence of Existing Defaults The Company is not in violation or default of (i) any provision of its Amended and Restated Memorandum and Articles of Association, (ii) the terms of any indenture, contract, lease, mortgage, deed of trust, note agreement, loan agreement or other agreement, obligation, condition, covenant or instrument to which it is a party or bound or to which its property is subject, or (iii) any (x) statute, law, rule, regulation, or (y) judgment, order or decree of any court, regulatory body, administrative agency, governmental body, arbitrator or other authority having jurisdiction over the Company; except in the case of clauses (ii) and (iii) above for any such conflict, breach or violation that would not, individually or in the aggregate, be reasonably expected to have a material adverse effect on the condition (financial or otherwise), prospects, earnings, business or properties of the Company, taken as a whole, whether or not arising from transactions in the ordinary course of business (a “Material Adverse Effect”).
Material Contract Defaults The Company is not in default in any material respect under the terms of any outstanding contract, agreement, lease, or other commitment which is material to the business, operations, properties, assets, or financial condition of either of them, and there is no event of default or other event which, with notice or lapse of time or both, would constitute a default in any material respect under any such contract, agreement, lease, or other commitment in respect of which the Company has not taken adequate steps to prevent such a default from occurring.