Common use of Non-Political Event Clause in Contracts

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or from (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, tsunami, chemical or radioactive contamination or ionising ionisation radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteResort and Project Infrastructure); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Resort and Project Infrastructure for a continuous period of [24 (twenty four) )] hours and an aggregate period exceeding [7 (seven) )] days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3Article 29.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor Contractor to deliver rolling stock or any critical equipment required for the Resort and Project Infrastructure and not available in India if such delay or failure is caused outside India by any event specified in Sub-clause Article (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractorContractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or from (g) any event or circumstances of a nature analogous to any of the foregoing.or

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteStation Premises); (b) strikes or boycotts (other than those involving the Concessionaire, Supplier and/or Developer Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Power Station for a continuous period of 24 (twenty four) hours and an aggregate period exceeding periodexceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political IndirectPolitical Event set forth in Clause 34.317.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Supplier and/or Developer by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India [or to supply Fuel from an overseas Captive Mine], if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire Supplier or Developer by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Supplier and/or Developer in any proceedings for reasons other than (i) failure of the Concessionaire Supplier and/or Developer to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authoritybythe Utility; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site Station Premises that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Station Premises; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, tsunami, chemical or radioactive contamination or ionising ionisation radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteResort and Project Infrastructure); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Resort and Project Infrastructure for a continuous period of [24 (twenty four) )] hours and an aggregate period exceeding [7 (seven) )] days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3Article 29.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor Contractor to deliver rolling stock or any critical equipment required for the Resort and Project Infrastructure and not available in India if such delay or failure is caused outside India by any event specified in Sub-clause Article (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractorContractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, ; or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, ; or (iii) enforcement of this Agreement, ; or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Project Site that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Project Site; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Siteinfrastructural facilities of the Service Provider); (b) strikes or boycotts (other than those involving the ConcessionaireService Provider, Railways, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3Article 19.3; (c) any failure or delay of a by the Railways and/or Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Service Provider by or on behalf of such the Railways and/or Contractor; (d) any delay or failure of an overseas contractor Contractor to deliver rolling stock or any equipment in India if such delay or failure is caused outside India by any event specified in Subsub-clause article (a) above and which does not result in any offsetting compensation being payable to the Concessionaire Service Provider by or on behalf of such contractorContractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Service Provider in any proceedings for reasons other than (i) failure of the Concessionaire Service Provider to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site Silos that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Silos; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority;; from (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteStation Premises); (b) strikes or boycotts (other than those involving the ConcessionaireSupplier, [Developer, if Supplier is a Trading Licensee] Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Power Station for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.317.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer if Supplier is a Trading Licensee] by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India [or to supply Fuel from an overseas Captive Mine], if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Developer if Supplier is a Trading Licensee] by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer if Supplier is a Trading Licensee] in any proceedings for reasons other than (i) failure of the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer if Supplier is a Trading Licensee] to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the AuthorityUtility; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site Station Premises that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Station Premises; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Any of the following events which prevent the Affected Party from performing any of its obligations for a continuous period of not less than 7 (seven) Days from the date of its occurrence, shall constitute a Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx DownloadedEvent: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/employees or representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.331.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment Equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause Clause 31.2 (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law Laws or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or from (g) any event or circumstances of a nature analogous to any of the foregoing.or

Non-Political Event. Downloaded from A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloadedxxx.xxxxxx.xxx (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteManufacturing Unit or Trainset Depots); (b) strikes or boycotts (other than those involving the ConcessionaireTechnology Partner, Contractors Sub- contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.332.3; (c) any failure or delay of a Sub-Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Technology Partner by or on behalf of such Sub-Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-Sub- clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire Technology Partner by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Technology Partner in any proceedings for reasons other than (i) failure of the Concessionaire Technology Partner to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the AuthorityGovernment; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site for Manufacturing Unit or Trainset Depots that could not reasonably have been expected to be discovered through a site inspection; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteStation Premises); (b) strikes or boycotts (other than those involving the ConcessionaireSupplier, [Developer, if Supplier is a Trading Licensee] Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Power Station for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.317.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer if Supplier is a Trading Licensee] by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India India, if such delay or failure is caused outside India by any event specified in Sub-Sub- clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Developer if Supplier is a Trading Licensee] by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer if Supplier is a Trading Licensee] in any proceedings for reasons other than (i) failure of the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer if Supplier is a Trading Licensee] to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the AuthorityUtility; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site Station Premises that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Station Premises; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. 29.2.1 A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act acts of God, epidemic, extremely adverse weather conditions, lightninglightening, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or chemical, radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteHotel and Project Infrastructure); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/employees / representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Hotel and Project Infrastructure for a continuous period of [24 (twenty four) )] hours and an aggregate period exceeding [7 (seven) )] days in an Accounting Year, and not being an Indirect Political Event Event, as set forth in Clause 34.3;29.3. (c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor Contractor to deliver rolling stock or any critical equipment required for the Hotel and Project Infrastructure and not available in India if such delay or failure is caused outside India by any event specified in Sub-clause Sub- Clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractorContractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or Permits (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Project Site that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Project Site; or fromor (g) any other event or circumstances circumstance of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloadedevents to the extent that they, or their consequences satisfy the requirements set forth in Clause 32.1 of this Agreement: (a) act of God, epidemicepidemic/ pandemic or plague, extremely adverse weather conditions, including lightning, earthquake, landslide, cyclone, flood, storm, typhoon, tornado, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to in the extent area of contamination or radiation or fire or explosion originating from a source external to the Project Site); (b) explosion, radioactive or chemical contamination or ionizing radiation directlyaffecting the Project, unless the source or cause of the explosion, contamination, radiation or hazardous thing is brought to or near the Project by the Affected Party or any contractor or sub-contractor of the Affected Party or any such affiliate or any of their respective employees, servants or agents; (c) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Project for a continuous period of 24 7 (twenty fourseven) hours days and an aggregate period exceeding 7 30 (seventhirty) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.332.3; (cd) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (de) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractorDeleted; (ef) any judgement judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (fg) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or fromor (gh) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, draught, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteStation Premises); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Renewable Hybrid Energy Project Facilities for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.316.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India India, if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the AuthorityMCGM; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site Station Premises that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Station Premises; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A 1) Any of the following events which prevent the Affected Party from performing any of its obligations for a continuous period of not less than 7 (seven) Days from the date of its occurrence, shall constitute a Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx DownloadedEvent: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal village Rampur to Naina Devi Ji Ropeway for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.329.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (fe) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or fromor (gf) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteStation Premises); (b) strikes or boycotts (other than those involving the ConcessionaireSupplier, [Developer, if Supplier is a Trading Licensee] Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Power Station for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.317.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer if Supplier is a Trading Licensee] by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India [or to supply Fuel from an overseas Captive Mine], if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by [Supplier if Supplier is NOT a Trading Licensee, or on behalf of such contractor;Developer if Supplier (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer if Supplier is a Trading Licensee] in any proceedings for reasons other than (i) failure of the Concessionaire [Supplier if Supplier is NOT a Trading Licensee, or Supplier and/or Developer ifSupplier is a Trading Licensee] to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the AuthorityAggregator; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site Station Premises that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Station Premises; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteStation Premises); (b) strikes or boycotts (other than those involving the ConcessionaireAggregator, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Power Station for a continuous period of 24 (twenty four) hours and an aggregate period exceeding periodexceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political IndirectPolitical Event set forth in Clause 34.317.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Aggregator by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractoromitted; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Aggregator in any proceedings for reasons other than (i) failure of the Concessionaire Aggregator to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authoritybythe Utility; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site Station Premises that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Station Premises; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloadedevents to the extent that they, or their consequences satisfy the requirements set forth in Clause 32.1 of this Agreement: (a) act of God, epidemicepidemic/ pandemic or plague, extremely adverse weather conditions, including lightning, earthquake, landslide, cyclone, flood, storm, typhoon, tornado, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to in the extent area of contamination or radiation or fire or explosion originating from a source external to the Project Site); (b) explosion, radioactive or chemical contamination or ionizing radiation directly affecting the Project, unless the source or cause of the explosion, contamination, radiation or hazardous thing is brought to or near the Project by the Affected Party or any contractor or sub-contractor of the Affected Party or any such affiliate or any of their respective employees, servants or agents; (c) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Project for a continuous period of 24 7 (twenty fourseven) hours days and an aggregate period exceeding 7 30 (seventhirty) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.332.3; (cd) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (de) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-sub- clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such overseas contractor; (ef) any judgement judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (fg) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or fromor (gh) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts or stoppage of work or ‘bandh’ (other than those involving the ConcessionaireMine Operator, Contractors or their respective employees/employees/ representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Mines for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Mine Operator by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-sub- clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire Mine Operator by or on behalf of such contractor; (e) any judgement judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Mine Operator in any proceedings proceeding for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iiiii) enforcement of this Agreement, or (iviii) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspectioninspection of the Site; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteStorage Facility); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Storage Facility for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.329.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or any critical equipment required for the Storage Facility and not available in India if such delay or failure is caused outside India by any event specified in Sub-Sub- clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteStation Premises); (b) strikes or boycotts (other than those involving the ConcessionaireSupplier, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Power Station for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.315.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Supplier by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India or to supply Fuel from an overseas Captive Mine, if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire Supplier by or on behalf of such contractor; (e) Non or part availability of open access, congestion/curtailment of transmission corridor. (f) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Supplier in any proceedings for reasons other than (i) failure of the Concessionaire Supplier to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the AuthorityProcurer; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or from (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, pandemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising ionisation radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteProject); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.331.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor Contractor to deliver rolling stock or any critical equipment required for the Project and not available in India if such delay or failure is caused outside India by any event specified in Sub-clause Article (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractorContractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, ; or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, ; or (iii) enforcement of this Agreement, ; or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Project Site that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Project Site; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Tourism Infrastructure Complex for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.318.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.

Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: xxx.xxxxxx.xxx Downloaded: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising ionisation radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteResort and Project Infrastructure); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal Resort and Project Infrastructure for a continuous period of [24 (twenty four) )] hours and an aggregate period exceeding [7 (seven) )] days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3Article 29.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor Contractor to deliver rolling stock or any critical equipment required for the Resort and Project Infrastructure and not available in India if such delay or failure is caused outside India by any event specified in Sub-clause Article (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractorContractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, ; or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, ; or (iii) enforcement of this Agreement, ; or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Project Site that could not reasonably have been expected to be discovered through a site inspectionan inspection of the Project Site; or fromor (g) any event or circumstances of a nature analogous to any of the foregoing.