Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 8 contracts
Samples: Concession Agreement, Concession Agreement, Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act Act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes Strikes or boycotts (other than those involving the ConcessionaireContractor, Contractors Sub-contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Highway for a continuous period of 24 (twenty twenty-four) hours and an aggregate period exceeding 7 10 (seventen) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.321.3;
(c) any Any failure or delay of a Contractor Sub-contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such ContractorEvent;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Contractor in any proceedings for reasons other than (i) failure of the Concessionaire Contractor to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 3 contracts
Samples: Contract Agreement, Contract Agreement, Contract Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, pandemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the ConcessionaireImplementation Agency, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.322.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Implementation Agency by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Implementation Agency in any proceedings for reasons other than (i) failure of the Concessionaire Implementation Agency to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 3 contracts
Samples: Development, Operation and Maintenance Agreement, Development, Operation and Maintenance Agreement, Development, Operation and Maintenance Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(ai) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(bii) strikes or boycotts (other than those involving the ConcessionaireContractors, Contractors or their respective employees/representatives, or attributable to any act or omission of by any of them) interrupting supplies and services to the Project for a continuous period of 24 48 (twenty fourforty eight) hours and an aggregate period exceeding 7 10 (seventen) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.3Article 8.2;
(ciii) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by Concessionaire, by, or on behalf of such Contractor;
(div) any judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (ia) its own failure of the Concessionaire to comply with any Applicable Law or Applicable PermitPermits, or (iib) on account of its own breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 2 contracts
Samples: Concession Agreement, Waste Supply Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemicepidemic or plague, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.334.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act Act of God, epidemic, extremely adverse weather conditions, lightning, . earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 7 (twenty fourseven) hours days and an aggregate period exceeding 7 30 (seventhirty) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.333.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the ConcessionaireContractor, Contractors Sub-contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Works for a continuous period of 24 (twenty twenty-four) hours and an aggregate period exceeding 7 10 (seventen) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.321.3;
(c) any failure or delay of a Contractor Sub-contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such ContractorEvent;
(d) any judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Contractor in any proceedings for reasons other than (i) failure of the Concessionaire Contractor to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Epc Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Highway for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.334.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than than
(i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of GodGod , epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing radiationionising radiation , fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/employees/ representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Highway for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven7(seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.334.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Non – Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons reason other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, Permit or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the ConcessionaireContractor, Contractors Sub-contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Highway for a continuous period of 24 (twenty twenty-four) hours and an aggregate period exceeding 7 10 (seventen) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.321.3;
(c) any failure or delay of a Contractor Sub-contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such ContractorEvent;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Contractor in any proceedings for reasons other than (i) failure of the Concessionaire Contractor to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Construction Contract
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the ConcessionaireContractor, Contractors Sub-contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Railway Project for a continuous period of 24 (twenty twenty-four) hours and an aggregate period exceeding 7 10 (seventen) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.319.3;
(c) any failure or delay of a Contractor Sub-contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such ContractorEvent;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Contractor in any proceedings for reasons other than (i) failure of the Concessionaire Contractor to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; or
Appears in 1 contract
Samples: Engineering, Procurement and Construction (Epc) Agreement
Non-Political Event. A Non-Political Event shall mean include one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site)explosion;
(b) strikes or boycotts or arson or theft (other than those involving the ConcessionaireStrategic Partner, Contractors Subcontractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services the Services to be provided with respect to the Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.323.3 below;
(c) any failure or delay of a Contractor Subcontractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Strategic Partner by or on behalf of such ContractorSubcontractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Strategic Partner in any proceedings for reasons other than (i) failure of the Concessionaire Strategic Partner to comply with any Applicable Law Laws or Applicable PermitPermits, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; or
(e) any event or circumstances of a nature analogous to any of the foregoing.
Appears in 1 contract
Samples: Technical Services Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) : a act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) ; b strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty 24(twenty-four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, Year and not being an Indirect Political Event set forth in Clause 28.3;
(c) Article27.3; c any failure or delay of a Contractor Subcontractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) Subcontractor; d any judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, ; or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, ; or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of GodGod , epidemicepidemic or plague, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing radiationionising radiation , fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representativesemployees/ representative, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Highway for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven7(seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.334.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Non – Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons reason other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, Permit or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the ConcessionaireOperator, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting a Contract Year, and not being an Indirect Political Event set forth in Clause 28.322.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire Operator by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Operator in any proceedings for reasons other than (i) failure of the Concessionaire Operator to comply with any Applicable Law or Applicable Permit, or (iin) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the SPV;
(e) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or
(f) any event or circumstances of a nature analogous to any of the foregoing.
Appears in 1 contract
Samples: Operation Services Agreement
Non-Political Event. A Non-Political Non‐Political Event shall mean one or more of the following acts or events:
(a) : a act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) ; b strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty four24(twenty‐four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, Year and not being an Indirect Political Event set forth in Clause 28.3;
(c) Article27.3; c any failure or delay of a Contractor Subcontractor but only to the extent caused by another Non-Non‐ Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) Subcontractor; d any judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, ; or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, ; or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty fourTwenty-Four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the ConcessionaireContractor, Contractors Sub-contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Highway for a continuous period of 24 (twenty twenty-four) hours and an aggregate period exceeding 7 10 (seventen) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.321.3;
(c) any failure or delay of a Contractor Sub-contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such ContractorEvent;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire Contractor in any proceedings for reasons other than (i) failure of the Concessionaire Contractor to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Construction Contract
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty twenty-four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.322.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, pandemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Road for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.327.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) a. act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionisation radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the SiteProject Facilities);
(b) b. strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project Facilities for a continuous period of [24 (twenty four) )] hours and an aggregate period exceeding [7 (seven) )] days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.325.3;
(c) c. any failure or delay of a Contractor but only to the extent caused by another Non-Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) d. any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, ; or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, ; or (iii) enforcement of this Agreement, or; or (iv) exercise of any of its rights under this Agreement by the Authority;
Appears in 1 contract
Samples: Concession Agreement
Non-Political Event. A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, . earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
Appears in 1 contract
Samples: Concession Agreement