Notice by Tenant Tenant shall give immediate notice to Landlord in case of fire or accidents in the Premises or in the building of which the Premises are a part or of defects therein or in any fixtures or equipment.
Inspection by Lessor Upon reasonable advance notice, Lessee, during reasonable business hours and subject to Lessee's security requirements, will make the Equipment and its related log and maintenance records available to Lessor for inspection.
Acceptance and Notice by Borrower Not later than (i) 11:00 a.m. (New York time) at least three Business Days prior to the proposed Borrowing Date, in the case of a Eurodollar Auction or (ii) 11:00 a.m. (New York time) on the proposed Borrowing Date, in the case of an Absolute Rate Auction (or, in either case upon reasonable prior notice to the Revolving Credit Lenders, such other time and date as the Borrower and the Administrative Agent may agree), the Borrower shall notify the Administrative Agent of its acceptance or rejection of the offers received by it pursuant to Section 2.3.4 or so notified to it pursuant to Section 2.3.5; provided, however, that the failure by the Borrower to give such notice to the Administrative Agent shall be deemed to be a rejection of all such offers. In the case of acceptance, such notice (a “Competitive Bid Borrowing Notice”) shall specify the aggregate principal amount of offers for each Interest Period that are accepted and (if the Administrative Agent is not the Competitive Bid Agent) shall include copies of each Competitive Bid Quote that is accepted. The Borrower may accept any Competitive Bid Quote in whole or in part (subject to the terms of Section 2.3.4(b)(iv) and (vi)); provided that: (i) the aggregate principal amount of each Competitive Bid Advance may not exceed (but, within the limitations set forth in Section 2.3.2(ii), may be less than) the applicable amount set forth in the related Competitive Bid Quote Request; (ii) acceptance of offers may only be made on the basis of ascending Eurodollar Bid Rates or Absolute Rates, as the case may be; and (iii) the Borrower may not accept any offer that is described in Section 2.3.4(c) or that otherwise fails to comply with the requirements of this Agreement.
Inspection by Landlord Landlord shall have the right to inspect the Tenant Improvements at all times, provided however, that Landlord’s failure to inspect the Tenant Improvements shall in no event constitute a waiver of any of Landlord’s rights hereunder nor shall Landlord’s inspection of the Tenant Improvements constitute Landlord’s approval of the same. Should Landlord disapprove any portion of the Tenant Improvements, Landlord shall notify Tenant in writing of such disapproval and shall specify the items disapproved. Any defects or deviations in, and/or disapproval by Landlord of, the Tenant Improvements shall be rectified by Tenant at no expense to Landlord, provided however, that in the event Landlord determines that a defect or deviation exists or disapproves of any matter in connection with any portion of the Tenant Improvements and such defect, deviation or matter might adversely affect the mechanical, electrical, plumbing, heating, ventilating and air conditioning or life-safety systems of the Building, the structure or exterior appearance of the Building or any other tenant’s use of such other tenant’s leased premises, Landlord may, take such action as Landlord deems necessary, at Tenant’s expense and without incurring any liability on Landlord’s part, to correct any such defect, deviation and/or matter, including, without limitation, causing the cessation of performance of the construction of the Tenant Improvements until such time as the defect, deviation and/or matter is corrected to Landlord’s satisfaction.
Termination by Lessee Subject to Subparagraph 18D, and without limiting any other rights and remedies to which Lessee may be entitled by common law, statutory law, or as elsewhere provided in this Lease, this Lease may be terminated by Lessee at any time after the happening, and during the existence, of one of more of the following events: i. The City’s permanent abandonment of the Premises at the Airport; ii. The lawful assumption by the United States Government, or any authorized agency thereof, of the operation, control, or use of the Airport, or any substantial part or parts thereof, that substantially restricts any sublessee from operating for at least one hundred fifty (150) calendar days; iii. The issuance by any court of competent jurisdiction of an injunction that prevents or restrains the use of the Airport or the Premises, that continues for at least one hundred fifty (150) calendar days; iv. The default by the City in the performance of any covenant or obligation on the part of the City to be performed, and the failure of the City to remedy the default for sixty (60) calendar days after receipt from Lessee of written notice to remedy the same; or v. Lessee’s decision to terminate the Lease as provided in Paragraph 11(B) of the Lease.
Termination by Lessor Lessor may terminate the lease at any time if any of the following shall happen:
Notice by Company The Company shall promptly notify the Trustee and the Paying Agent of any facts known to the Company that would cause a payment of any Obligations with respect to the Notes to violate this Article 10, but failure to give such notice shall not affect the subordination of the Notes to the Senior Debt as provided in this Article 10.
Acceptance by Recipient This Agreement must be signed by the Chief Executive Officer of the Recipient and returned to, and received by, the OPWC within forty-five (45) days of the date written on the first page of this Agreement. Failure of the Recipient to return a fully executed copy of this Agreement to the OPWC within the forty-five (45) day limit will result in this Agreement being declared null and void. However, upon the Recipient presenting the Director with a written explanation of the need to extend this forty-five (45) day limit, the Director, in his sole discretion, may extend the forty-five (45) day limit.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Termination by Landlord If the Resident fails to adhere to the Community Standards and House Rules, or fails to perform and observe any of the terms or conditions of this Residence Agreement, the Landlord, at its option and in its sole discretion, may terminate the Term created by this Residence Agreement upon giving the Resident written notice of the Landlord’s intention to do so, to take effect within no less than forty-eight (48) hours from receipt of a Notice to Vacate from the Landlord. Notwithstanding the foregoing, a Resident may be immediately evicted from the Premises and Residence for reasons including but not limited to assault of any kind, any offence resulting in a criminal charge, any destruction of property, or if the Resident is deemed a safety concern for the community. The Resident is liable to pay all legal costs incurred by the Landlord in enforcing the provisions of this Residence Agreement including obtaining possession of the Premises.
