Malfunctions See above.
Loss or Damage Lessee hereby assumes and shall bear the entire risk of any loss, theft, damage to, or destruction of, any unit of Equipment from any cause whatsoever from the time the Equipment is shipped to Lessee.
ACCIDENTAL DAMAGE IN HANDLING ( “ADH”): If purchased, the Covered Product is protected against accidental damage in handling such as drops and liquid spills. Immersion of Your Covered Product is not covered under this Agreement. ADH only covers operational or mechanical failure caused by a single incident while handling and does not include protection against theft, mysterious disappearance, misplacement, viruses or reckless, abusive, willful or intentional misconduct associated with handling and/or use of the Covered Product, cosmetic damage and/or other damage that does not affect the unit’s functionality, damage caused during shipment between You and Our service providers and any other limitations listed in the “What is Not Covered” section of this Agreement. For the purpose of this Agreement, Accidental Damage is defined as a single, unexpected, sudden and unintentional event and does not include accumulated damage from continual or multiple events. The use of this coverage requires an explanation of where and when the Accidental Damage occurred as well as a detailed description of the actual event. If needed, the replacement value of the Covered Product will be solely determined by the Administrator of this Agreement.
CASUALTY DAMAGE A. If all or any part of the Premises is damaged by fire or other casualty, Tenant shall immediately notify Landlord in writing. During any period of time that all or a material portion of the Premises is rendered untenantable as a result of a fire or other casualty, the Rent shall xxxxx for the portion of the Premises that is untenantable and not used by Tenant. Landlord shall have the right to terminate this Lease if: (1) the Building or the Project shall be damaged so that, in Landlord’s reasonable judgment, substantial alteration or reconstruction of the Building or the Project shall be required (whether or not the Premises has been damaged); (2) Landlord is not permitted by Law to rebuild the Building or the Project in substantially the same form as existed before the fire or casualty; (3) the Premises have been materially damaged and there is less than eighteen (18) months of the Term remaining on the date of the casualty; (4) any Mortgagee requires that the insurance proceeds be applied to the payment of the mortgage debt; or (5) a material uninsured loss to the Building or the Project occurs. Landlord may exercise its right to terminate this Lease by notifying Tenant in writing within 90 days after the date of the casualty. If Landlord does not terminate this Lease, Landlord shall commence and proceed with reasonable diligence to repair and restore the Building and the Premises Improvements (excluding any Alterations that were performed by Tenant in violation of this Lease). However, in no event shall Landlord be required to spend more than the insurance proceeds received by Landlord. Landlord shall not be liable for any loss or damage to Tenant’s Property or to the business of Tenant resulting in any way from the fire or other casualty or from the repair and restoration of the damage. Landlord and Tenant hereby waive the provisions of any Law relating to the matters addressed in this Article, and agree that their respective rights for damage to or destruction of the Premises shall be those specifically provided in this Lease. Tenant shall have the right to terminate this Lease i 1: (a) a substantial portion of the Premises has been damaged by fire or other casualty and such damage cannot reasonably be repaired (as reasonably determined by Landlord) within 60 days after Landlord’s receipt of all required permits to restore the Premises; (b) there is less than eighteen (18) months of the Term remaining on the date of such casualty; and (c) Tenant provides Landlord with written notice of its intent to terminate within thirty (30) days after the date of the fire or other casualty.
Accidents If a death, serious personal injury or substantial property damage occurs in connection with CONTRACTOR’s performance of this Agreement, CONTRACTOR shall immediately notify Mendocino County Risk Manager's Office by telephone. CONTRACTOR shall promptly submit to COUNTY a written report, in such form as may be required by COUNTY of all accidents which occur in connection with this Agreement. This report must include the following information: (1) name and address of the injured or deceased person(s); (2) name and address of CONTRACTOR's sub-contractor, if any; (3) name and address of CONTRACTOR's liability insurance carrier; and (4) a detailed description of the accident and whether any of COUNTY's equipment, tools, material, or staff were involved.
Safety, breakdowns and accidents 17.5.1 The Concessionaire shall ensure safe conditions for the Users and passengers, and in the event of unsafe conditions, it shall follow the relevant operating procedures and undertake removal of obstruction and debris without delay. Such procedures shall conform to the provisions of this Agreement, Applicable Laws, Applicable Permits and Good Industry Practice.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
CLOSURE TO PREVENT DAMAGE In accordance with Contract Clause G-220 STATE SUSPENDS OPERATION, the Contract Administrator will suspend road work or hauling right-of-way timber, forest products, or rock under the following conditions: Wheel track rutting exceeds 6 inches on roads. Surface or base stability problems persist. Weather is such that satisfactory results cannot be obtained in an area of operations. When, in the opinion of the Contract Administrator excessive road damage or rutting may occur. Operations must stop unless authority to continue working or hauling is granted in writing by the Contract Administrator. In the event that surface or base stability problems persist, Purchaser shall cease operations, or perform corrective maintenance or repairs, subject to specifications within this road plan. Before and during any suspension, Purchaser shall protect the work from damage or deterioration.
Accidental Damage The service contract provides protection against accidental damage to the covered product (for example: falling off Your hands, or a car, or water damage) resulting from the handling of such product and that is not intentionally caused by You. IF YOU NEED SERVICE: To locate or arrange for service, call the toll free number on the Schedule Page. We will select an Authorized Repair Center which will contact You to arrange for Your service. You should contact Us if the completion of Your repair is not satisfactory.
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
