Notice of Claims If the City or Contractor receives notice of any claim or circumstances which could give rise to an indemnified loss, the receiving Party shall give written notice to the other Party within 30 days. The notice must include the following:
Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.
Notice of Claim Reduction of Policy Limits The Consulting Engineer/Architect, upon receipt of notice of any claim in connection with the Contract, shall promptly notify the City, providing full details thereof, including an estimate of the amount of loss or liability. The Consulting Engineer/Architect shall monitor and promptly notify the City of any reduction in limits of protection afforded under any policy listed in the Certificate (or otherwise required by the contract) if the Consulting Engineer/Architect’s limits of protection shall have been impaired or reduced to such extent that the limits fall below the minimum amounts required herein. The Consulting Engineer/Architect shall promptly reinstate the original limits of liability required hereunder and shall furnish evidence thereof to the City.
Release of Claims by Holders Each Holder hereby releases the Representative for all claims arising from the Representative’s performance of its services pursuant to this Revenue Sharing Agreement, except and to the extent that a Holder can demonstrate by clear and convincing evidence that such act or omission constituted gross negligence or intentional misconduct.
All Claims Must be Arbitrated It is the intention of the parties that this agreement bind all parties whose claims may arise out of or relate to treatment or service provided by the physician including any spouse or heirs of the patient and any children, whether born or unborn at the time of the occurrence giving rise to any claim. In the case of any pregnant mother, the term “patient” herein shall mean both the mother and the mother’s expected child or children. All claims for monetary damages exceeding the jurisdictional limit of the small court against the physician, and physician’s partners, associates, association, corporation partnership, and the employees, agents, and estates of any of them, must be arbitrated including, without limitation, claims for loss of consortium, wrongful death, emotional distress, or punitive damages. Filing any action in any court by the physician to collect any fee from the patient shall not waive the right to compel arbitration of any malpractice claim.
NOTICE OF INDEMNIFICATION CLAIMS If the Town seeks indemnification pursuant to this Article 13.2, it shall notify Competitive Supplier of the existence of a claim, or potential claim as soon as practicable after learning of such claim, or potential claim, describing with reasonable particularity the circumstances giving rise to such claim. Upon written acknowledgment by the Competitive Supplier that it will assume the defense and indemnification of such claim, the Competitive Supplier may assert any defenses which are or would otherwise be available to the Town.
Defense of Claims Subject to the provisions of applicable policies of directors’ and officers’ liability insurance, if any, the Company shall be entitled to participate in the defense of any Indemnifiable Claim or to assume or lead the defense thereof with counsel reasonably satisfactory to the Indemnitee; provided that if Indemnitee determines, after consultation with counsel selected by Indemnitee, that (a) the use of counsel chosen by the Company to represent Indemnitee would present such counsel with an actual or potential conflict, (b) the named parties in any such Indemnifiable Claim (including any impleaded parties) include both the Company and Indemnitee and Indemnitee shall conclude that there may be one or more legal defenses available to him or her that are different from or in addition to those available to the Company, (c) any such representation by such counsel would be precluded under the applicable standards of professional conduct then prevailing, or (d) Indemnitee has interests in the claim or underlying subject matter that are different from or in addition to those of other Persons against whom the Claim has been made or might reasonably be expected to be made, then Indemnitee shall be entitled to retain separate counsel (but not more than one law firm plus, if applicable, local counsel in respect of any particular Indemnifiable Claim for all indemnitees in Indemnitee’s circumstances) at the Company’s expense. The Company shall not be liable to Indemnitee under this Agreement for any amounts paid in settlement of any threatened or pending Indemnifiable Claim effected without the Company’s prior written consent. The Company shall not, without the prior written consent of the Indemnitee, effect any settlement of any threatened or pending Indemnifiable Claim which the Indemnitee is or could have been a party unless such settlement solely involves the payment of money and includes a complete and unconditional release of the Indemnitee from all liability on any claims that are the subject matter of such Indemnifiable Claim. Neither the Company nor Indemnitee shall unreasonably withhold its consent to any proposed settlement; provided that Indemnitee may withhold consent to any settlement that does not provide a complete and unconditional release of Indemnitee.
Claim Form i. Within 15 days after receiving a notice of a claim, you or your Dental Provider will be provided with a Claim Form to make claim for Benefits. To make a claim, the form should be completed and signed by the Provider who performed the services, and by the patient (or the parent or guardian if the patient is a minor), and submitted to the address above.
Submission of Claims 39 If Provider submits claims for Services rendered under this Contract, the following 40 requirements shall apply:
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
