Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.
Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.
Notice of Claims If the City or Contractor receives notice of any claim or circumstances which could give rise to an indemnified loss, the receiving Party shall give written notice to the other Party within 30 days. The notice must include the following:
Sending a Claim Notice Before beginning a lawsuit, mediation or arbitration, you and we agree to send a written notice (a claim notice) to each party against whom a claim is asserted, in order to provide an opportunity to resolve the claim informally or through mediation. Go to xxxxxxxxxxxxxxx.xxx/ claim for a sample claim notice. The claim notice must describe the claim and state the specific relief demanded. Notice to you may be provided by your billing statement or sent to your billing address. Notice to us must include your name, address and Account number and be sent to American Express ADR c/o CT Corporation System, 00 Xxxxxxx Xxxxxx, Xxx Xxxx, Xxx Xxxx 00000. If the claim proceeds to arbitration, the amount of any relief demanded in a claim notice will not be disclosed to the arbitrator until after the arbitrator rules.
Termination Payment for Force Majeure Event 34.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 90% (ninety per cent) of the Debt Due less Insurance Cover.
Application for Payment The form acceptable to Owner that is to be used by the Contractor during the course of the Work in requesting payment from the Owner and that is to be accompanied by such supporting documentation as is required by the Contract Documents.
Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.
Billing, Payment, Milestones and Financial Security
Invoice Format Invoices furnished by Contractor under this Agreement must be in a form acceptable to the Controller and City, and must include a unique invoice number. Payment shall be made by City as specified in 3.3.6 or in such alternate manner as the Parties have mutually agreed upon in writing.
Final Meeting Benefits Questionnaire Provide all key assumptions used to estimate projected benefits, including targeted market sector (e.g., population and geographic location), projected market penetration, baseline and projected energy use and cost, operating conditions, and emission reduction calculations. Examples of information that may be requested in the questionnaires include:
