Notice of IRS or TWC Insolvency Grantee will send notice to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx, their insolvency, incapacity or outstanding unpaid obligations to the Internal Revenue Service (IRS) or Texas Workforce Commission (TWC) within five (5) days of the date of becoming aware of such.
No Felony Criminal Convictions Contractor represents that neither Contractor nor any of its employees, agents, or representatives, including any subcontractors and employees, agents, or representative of such subcontractors, have been convicted of a felony criminal offense or that if such a conviction has occurred Contractor has fully advised System Agency in writing of the facts and circumstances surrounding the convictions.
Notice of Material Breach and Intent to Exclude The parties agree that a material breach of this IA by Xxxxx constitutes an independent basis for Xxxxx’x exclusion from participation in the Federal health care programs. The length of the exclusion shall be in the OIG’s discretion, but not more than three years per material breach. Upon a determination by OIG that Xxxxx has materially breached this IA and that exclusion is the appropriate remedy, OIG shall notify Xxxxx of: (a) Xxxxx’x material breach; and (b) OIG’s intent to exercise its contractual right to impose exclusion. (This notification shall be referred to as the “Notice of Material Breach and Intent to Exclude.”)
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Notification of Legal Requests Contractor shall immediately notify City upon receipt of any subpoenas, service of process, litigation holds, discovery requests and other legal requests (“Legal Requests”) related to all data given to Contractor by City in the performance of this Agreement (“City Data” or “Data”), or which in any way might reasonably require access to City’s Data, and in no event later than 24 hours after it receives the request. Contractor shall not respond to Legal Requests related to City without first notifying City other than to notify the requestor that the information sought is potentially covered under a non-disclosure agreement. Contractor shall retain and preserve City Data in accordance with the City’s instruction and requests, including, without limitation, any retention schedules and/or litigation hold orders provided by the City to Contractor, independent of where the City Data is stored.
Criminal Convictions Grantee certifies that neither it nor any officer, director, partner or other managerial agent of Grantee has been convicted of a felony under the Xxxxxxxx-Xxxxx Act of 2002, nor a Class 3 or Class 2 felony under Illinois Securities Law of 1953, or that at least five (5) years have passed since the date of the conviction. Grantee further certifies that it is not barred from receiving an Award under 30 ILCS 500/50-10.5, and acknowledges that Grantor shall declare the Agreement void if this certification is false (30 ILCS 500/50-10.5).
Notice of Grievance Until Borrower or Lender has notified the other party (in accordance with Section 16) of an alleged breach and afforded the other party a reasonable period after the giving of such notice to take corrective action, neither Borrower nor Lender may commence, join, or be joined to any judicial action (either as an individual litigant or a member of a class) that (a) arises from the other party’s actions pursuant to this Security Instrument or the Note, or (b) alleges that the other party has breached any provision of this Security Instrument or the Note. If Applicable Law provides a time period that must elapse before certain action can be taken, that time period will be deemed to be reasonable for purposes of this Section 23. The notice of Default given to Borrower pursuant to Section 26(a) and the notice of acceleration given to Borrower pursuant to Section 19 will be deemed to satisfy the notice and opportunity to take corrective action provisions of this Section 23.
Electronic Posting of Notice of Intended Award Based on the evaluation, on the date indicated in the Timeline of Events the Department shall electronically post a Notice of Intended Award on the VBS and the MFMP Sourcing website for review by interested parties at the time and location specified in the Timeline of Events. The Notice of Intended Award shall remain posted for a period of seventy-two (72) hours, not including weekends or State observed holidays. If the notice of award is delayed, in lieu of posting the notice of intended award the Department may post a notice of the delay and a revised date for posting the notice of intended award.
Waiver of Appellate and Post-Conviction Rights a. The defendant acknowledges, understands and agrees that by pleading guilty pursuant to this plea agreement he waives his right to appeal or collaterally attack a finding of guilt following the acceptance of this plea agreement, except on grounds of (1) ineffective assistance of counsel; or (2) prosecutorial misconduct.
Notice of Legal Actions The Contractor must notify the Department of any legal actions filed against it for a violation of any laws, rules, codes, ordinances or licensing requirements within 30 days of the action being filed. The Contractor must notify the Department of any legal actions filed against it for a breach of a contract of similar size and scope to this Contract within 30 days of the action being filed. Failure to notify the Department of a legal action within 30 days of the action will be grounds for termination for cause of the Contract.
