Unconditional Right of Holders to Receive Principal, Premium and Interest and to Convert Notwithstanding any other provision in this Indenture, the Holder of any Security shall have the right, which is absolute and unconditional, to receive payment of the principal of and any premium and (subject to Section 307) interest on such Security on the respective Stated Maturities expressed in such Security (or, in the case of redemption, on the Redemption Date), and, if the terms of such Security so provide, to convert such Security in accordance with its terms, and to institute suit for the enforcement of any such payment and, if applicable, any such right to convert, and such rights shall not be impaired without the consent of such Holder.
Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
Failure to Consummate a Business Combination; Trust Account Waiver (a) The Sponsor and each Insider hereby agree, with respect to itself, herself or himself, that in the event that the Company fails to consummate its initial Business Combination within the time period set forth in the Charter, the Sponsor and each Insider shall take all reasonable steps to cause the Company to (i) cease all operations except for the purpose of winding up; (ii) as promptly as reasonably possible but not more than 10 business days thereafter, redeem 100% of the Public Shares, at a per-share price, payable in cash, equal to the aggregate amount then on deposit in the Trust Account, including interest earned on the funds held in the Trust Account and not previously release to the Company to pay income taxes (less up to $100,000 of interest to pay dissolution expenses), divided by the number of then outstanding Public Shares, which redemption will completely extinguish Public Shareholders’ rights as shareholders (including the right to receive further liquidation distributions, if any); and (iii) as promptly as reasonably possible following such redemption, subject to the approval of the Company’s remaining shareholders and the Board, liquidate and dissolve, subject in the case of clauses (ii) and (iii) to the Company’s obligations under Cayman Islands law to provide for claims of creditors and in all cases subject to the other requirements of applicable law. The Sponsor and each Insider agree not to propose any amendment to the Charter (i) that would modify the substance or timing of the Company’s obligation to provide holders of the Public Shares the right to have their shares redeemed in connection with an initial Business Combination or to redeem 100% of the Public Shares if the Company does not complete an initial Business Combination within the required time period set forth in the Charter or (ii) with respect to any provision relating to the rights of holders of Public Shares unless the Company provides its Public Shareholders with the opportunity to redeem their Public Shares upon approval of any such amendment at a per-share price, payable in cash, equal to the aggregate amount then on deposit in the Trust Account, including interest earned on the funds held in the Trust Account and not previously released to the Company to pay taxes, if any, divided by the number of then-outstanding Public Shares.
Notice of Events of Default The Issuer shall give a Responsible Officer of the Indenture Trustee and each Rating Agency prompt written notice of each Event of Default hereunder and each default on the part of the Servicer or the Seller of its obligations under the Sale and Servicing Agreement.
Waiver of Redemption, Notice and Marshalling of Assets To the fullest extent permitted by law, Mortgagor hereby irrevocably and unconditionally waives and releases (a) all benefit that might accrue to Mortgagor by virtue of any present or future statute of limitations or law or judicial decision exempting the Mortgaged Property from attachment, levy or sale on execution or providing for any stay of execution, exemption from civil process, redemption or extension of time for payment, (b) all notices of any Event of Default or of Mortgagee’s election to exercise or the actual exercise of any right, remedy or recourse provided for under the Loan Documents, and (c) any right to a marshalling of assets or a sale in inverse order of alienation.
Notice of Delay Within Fourteen (14) days after the date of occurrence of any cause of delay, on account of which the BUILDER claims that it is entitled under this Contract to a postponement of the Delivery Date, the BUILDER shall notify the BUYER in writing or by telefax confirmed in writing of the date when such cause of delay occurred. Likewise, within Fourteen (14) days after the date of ending of such cause of delay, the BUILDER shall notify the BUYER in writing or by xxxxxxx confirmed in writing of the date when such cause of delay ended. The BUILDER shall also notify the BUYER of the period, by which the Delivery Date is postponed by reason of such cause of delay, with all reasonable dispatch after it has been determined. If the BUILDER does not give the timely advice as above, the BUILDER shall lose the right to claim such delays as permissible delay. Failure of the BUYER to acknowledge to the BUILDER’s claim for postponement of the Delivery Date within Fourteen (14) days after receipt by the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER of its right to object to such postponement of the Delivery Date.
Notice to Allow Conversion by Xxxxxx If (A) the Company shall declare a dividend (or any other distribution in whatever form) on the Common Stock, (B) the Company shall declare a special nonrecurring cash dividend on or a redemption of the Common Stock, (C) the Company shall authorize the granting to all holders of the Common Stock of rights or warrants to subscribe for or purchase any shares of capital stock of any class or of any rights, (D) the approval of any stockholders of the Company shall be required in connection with any reclassification of the Common Stock, any consolidation or merger to which the Company is a party, any sale or transfer of all or substantially all of the assets of the Company, or any compulsory share exchange whereby the Common Stock is converted into other securities, cash or property or (E) the Company shall authorize the voluntary or involuntary dissolution, liquidation or winding up of the affairs of the Company, then, in each case, the Company shall cause to be filed at each office or agency maintained for the purpose of conversion of this Note, and shall cause to be delivered to the Holder at its last address as it shall appear upon the Note Register, at least twenty (20) calendar days prior to the applicable record or effective date hereinafter specified, a notice stating (x) the date on which a record is to be taken for the purpose of such dividend, distribution, redemption, rights or warrants, or if a record is not to be taken, the date as of which the holders of the Common Stock of record to be entitled to such dividend, distributions, redemption, rights or warrants are to be determined or (y) the date on which such reclassification, consolidation, merger, sale, transfer or share exchange is expected to become effective or close, and the date as of which it is expected that holders of the Common Stock of record shall be entitled to exchange their shares of the Common Stock for securities, cash or other property deliverable upon such reclassification, consolidation, merger, sale, transfer or share exchange, provided that the failure to deliver such notice or any defect therein or in the delivery thereof shall not affect the validity of the corporate action required to be specified in such notice. To the extent that any notice provided hereunder constitutes, or contains, material, non-public information regarding the Company or any of the Subsidiaries, the Company shall simultaneously file such notice with the Commission pursuant to a Current Report on Form 8-K. The Holder shall remain entitled to convert this Note during the 20-day period commencing on the date of such notice through the effective date of the event triggering such notice except as may otherwise be expressly set forth herein.
Reservation of Shares Issuable Upon Conversion The Company covenants that it will at all times reserve and keep available out of its authorized and unissued shares of Common Stock for the sole purpose of issuance upon conversion of this Debenture and payment of interest on this Debenture, each as herein provided, free from preemptive rights or any other actual contingent purchase rights of Persons other than the Holder (and the other holders of the Debentures), not less than such aggregate number of shares of the Common Stock as shall (subject to the terms and conditions set forth in the Purchase Agreement) be issuable (taking into account the adjustments and restrictions of Section 5) upon the conversion of the outstanding principal amount of this Debenture and payment of interest hereunder. The Company covenants that all shares of Common Stock that shall be so issuable shall, upon issue, be duly authorized, validly issued, fully paid and nonassessable and, if the Registration Statement is then effective under the Securities Act, shall be registered for public sale in accordance with such Registration Statement.
Redemption Notice To call any Notes for Redemption, the Company must send to each Holder of such Notes, the Trustee and the Paying Agent a written notice of such Redemption (a “Redemption Notice”). Such Redemption Notice must state:
Notice to the Holder Whenever the Conversion Price is adjusted pursuant to any provision of this Section 5, the Company shall deliver to each Holder within two (2) Business Days a notice setting forth the Conversion Price after such adjustment and setting forth a brief statement of the facts requiring such adjustment.
