Notice of Delay. 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
Notice of Delay. If there is a delay of your occupancy and we haven’t given notice of delay as set forth immediately below, you may terminate this Lease up to the date when the apartment is ready for occupancy, but not later.
(a) If we give written notice to any of you or your occu- pants when or after the Lease begins—and the notice states that occupancy has been delayed because of construction or a previous resident’s holding over, and that the apartment will be ready on a specific date— you may terminate the Lease within 3 days after you receive written notice, but no later.
(b) If we give any of you written notice before the date the Lease begins and the notice states that a construction delay is expected and that the apartment will be ready for you to occupy on a specific date, you may termi- nate the Lease within 7 days after receiving written no- xxxx, but no later. The readiness date stated in the writ- ten notice becomes the new effective Lease date for all purposes. This new date can’t be moved to an earlier date unless we and you agree in writing.
Notice of Delay. Within Fourteen (14) days after the date of occurrence of any cause of delay, on account of which the BUILDER claims that it is entitled under this Contract to a postponement of the Delivery Date, the BUILDER shall notify the BUYER in writing or by telefax confirmed in writing of the date when such cause of delay occurred. Likewise, within Fourteen (14) days after the date of ending of such cause of delay, the BUILDER shall notify the BUYER in writing or by xxxxxxx confirmed in writing of the date when such cause of delay ended. The BUILDER shall also notify the BUYER of the period, by which the Delivery Date is postponed by reason of such cause of delay, with all reasonable dispatch after it has been determined. If the BUILDER does not give the timely advice as above, the BUILDER shall lose the right to claim such delays as permissible delay. Failure of the BUYER to acknowledge to the BUILDER’s claim for postponement of the Delivery Date within Fourteen (14) days after receipt by the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER of its right to object to such postponement of the Delivery Date.
Notice of Delay. Whenever any occurrence or event affecting Seller or its subcontractors or suppliers delays or threatens to delay the timely performance of this Agreement, Seller shall immediately give written notice thereof to Buyer.
Notice of Delay. The Contractor shall notify the Government if the contractor receives a notice of any change in the work, or if any other conditions arise that may cause or are actually causing delays and the Contractor believes may result in completion of the project after the completion date. The notification shall state the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule or the completion date should be revised. The Contractor shall give such notice promptly, not more than ten (10) days following the first occurrence of event giving rise to the delay or prospective delay. The Contractor shall obtain the approval of the Contracting Officer for any revisions to the approved time schedule.
Notice of Delay. As soon as possible after and in any event within seven (7) days after the date of the commencement of any cause of delay, on account of which the SELLER claims that it is entitled under this Contract to a postponement of the Delivery Date excluding days due to arbitration, the SELLER shall notify the BUYER in writing or by telex or facsimile confirmed in writing of the date when such cause of delay commenced and the reasons thereof, and the estimated duration of the probable delay in delivery of the VESSEL, and shall provide the BUYER, if available, evidence to justify the delay claimed. Likewise, within seven (7) days after the date of ending of such cause of delay, the SELLER shall notify the BUYER in writing or by telex or facsimile confirmed in writing of the date when such cause of delay ended. In any event the SELLER shall also notify the BUYER of the period of time by which the SELLER claims the Delivery Date should be postponed by reason of such cause of delay within the same seven (7) day period as aforesaid. Failure of the SELLER to notify the BUYER of its claim for postponement of the Delivery Date within a period of seven (7) days from the date of cessation of the event causing the delay shall be deemed a waiver of its claim. Failure of the BUYER to object to the SELLER’s claim for postponement of the Delivery Date within Fourteen (14) days after receipt by the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER of its right to object to such postponement of the Delivery Date. The burden of proof shall always be on the SELLER to establish the facts entitling it to rely on this Clause and that due notices were given and that it has taken all reasonable steps to avoid or mitigate the delay.
Notice of Delay. CONSULTANT shall, immediately upon ascertainment, notify DISTRICT in writing of any delay in: (i) the preparation and/or production of any of CONSULTANT's documents hereunder; (ii) the performance by DISTRICT's consultants; (iii) CONSULTANT's services; or (iv) in connection with any matter attended to by CONSULTANT or with which CONSULTANT is familiar (whether or not as the result of an act or omission of another) which would affect or delay each Service Delivery Schedule. CONSULTANT shall consult and advise with DISTRICT in connection with any such delay and its effect on the Service Delivery Schedule and shall take such action on DISTRICT's behalf as DISTRICT may request in accordance with the terms and conditions of this Agreement.
Notice of Delay. (a) As soon as practically possible, but not later than ten (10) days after the commencement of any cause of delay, on account of which Builder claims that it is entitled under this Contract to a postponement of the Delivery Date, Builder shall (if practically possible) notify Buyer of the dates, the cause of delay which has occurred and its expected duration.
(b) Within ten (10) days after the ending of such cause of delay the Builder shall notify Buyer in writing of the date such cause of delay ended.
(c) Builder shall also notify Buyer of the period by which the Delivery Date is postponed by reason of such cause of delay with all reasonable despatch after it has been determined. Failure by Buyer to object to Builder’s claim for postponement of the Delivery Date within fourteen (14) days after receipt by Buyer of such notice of claim shall be deemed to be a waiver by Buyer of its right to object to such postponement of the Delivery Date.
(d) Failure of the Builder to notify the Buyer of any causes of delay as specified in Article VIII.1 and any other causes of delays which, under the terms of this Contract, are to be considered as permissible delays, shall preclude the Builder from claiming Force Majeure for such event.
Notice of Delay. Within five (5) business days from the date of commencement of any delay on account of which the SELLER claims that it is entitled under this Contract to an extension of the time for delivery of the VESSEL, the SELLER shall advise the BUYER by telefax, of the date such delay commenced, and the detailed reasons therefore. Date: 13th November, 2013 Likewise within five (5) business days after such delay ends, the SELLER shall advise the BUYER in writing or by telefax, of the date such delay ended, and also shall specify the period of time by which it claims the Contractual Delivery Date is extended by reason of such delay. Failure of the BUYER to respond to the SELLER's notification and claim for extension of the Delivery Date within twenty one (21) days after receipt by the BUYER of such notification, shall be deemed to be a waiver by the BUYER of its right to object to such extension. Failure by the SELLER to give any such notice, as is required therein above, shall disentitle the SELLER from claiming a postponement of the Delivery Date.
Notice of Delay. Lessee shall give to Lessor prompt written notice of any fire, explosion, accident, flood, storm, earthquake or other casualty or strike, lock out, act of God or interruption of the construction of the Project which is reasonably anticipated to interfere with the ability of Lessee to complete the Project by the Completion Date.
