Common use of NOTICE TO THE GOVERNMENT OF DELAYS Clause in Contracts

NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the COTR, in writing, giving pertinent details, provided, however, that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract.

NOTICE TO THE GOVERNMENT OF DELAYS. (a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the COTRContracting Officer’s Representative, in writing, giving pertinent details, provided, however, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract.

NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer CO and the COTRCOR, in writing, giving pertinent details, provided, however, that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract.

NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it the contractor anticipates difficulty in complying with the contract delivery schedule or completion date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer Officer, and the COTRCOR, in writing, giving pertinent details, provided, however, that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule date, or date or of any rights or remedies provided by law or under this contract. *Portions of this exhibit have been excluded because it both (i) is not material and (ii) would be competitively harmful if publicly disclosed.

NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer CO and the COTRCOR, in writing, giving pertinent details, provided, however, that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government BEP of any delivery schedule or date or of any rights or remedies provided by law or under this contract.