NOTICE TO THE GOVERNMENT OF LABOR DISPUTES. 1. If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of the Contract, the Contractor must immediately give notice, including all relevant information, to the Transition to Operations Coordinator or the Contract Officer.
Appears in 3 contracts
Samples: Contract for the Purchase, bid.oregonstate.edu, bid.oregonstate.edu
NOTICE TO THE GOVERNMENT OF LABOR DISPUTES. 1. If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of the Contract, the Contractor must immediately give notice, including all relevant information, to the Transition to Operations Coordinator Departmental Administrator or the Contract Officer.
Appears in 2 contracts
Samples: bid.oregonstate.edu, bid.oregonstate.edu
NOTICE TO THE GOVERNMENT OF LABOR DISPUTES. 1. If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of the Contractthis contract, the Contractor must shall immediately give notice, including all relevant information, to the Transition to Operations Coordinator or the Contract Contracting Officer.
Appears in 1 contract
Samples: photos.state.gov
NOTICE TO THE GOVERNMENT OF LABOR DISPUTES. 1. (FEB 1997) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of the Contractthis contract, the Contractor must shall immediately give notice, including all relevant information, to the Transition to Operations Coordinator or the Contract Contracting Officer.
Appears in 1 contract
Samples: Cooperative Purchasing Agreement