NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information, whether Buyer has requested such status or not. When requested by Buyer, Seller will in a timely manner provide status on labour contracts and pending negotiations and prepare a contingency plan including incurred costs to address potential disruptions to the satisfaction of Buyer acting reasonably. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this PO, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Supplier knows or, in the exercise of reasonable judgment, should know, that any actual or potential labor dispute is delaying or threatens to delay Supplier’s timely performance of the Purchase Order, Supplier shall immediately provide written notice and all relevant information relating thereto to Buyer. Supplier shall insert the substance of this Paragraph 17 in any subcontract as to which a labor dispute may delay the timely performance of the Purchase Order.
NOTICE TO BUYER OF LABOR DISPUTES. (a) Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information to Buyer.
(b) Xxxxxx agrees to insert the substance of this article, including this paragraph (b), in any subcontract hereunder.
NOTICE TO BUYER OF LABOR DISPUTES. Whenever an actual or potential labor dispute is delaying or threatening to delay the performance of this Agreement, Seller shall immediately give notice thereof to Buyer. Such notice shall include all relevant information with respect to such disputes.
NOTICE TO BUYER OF LABOR DISPUTES. (a) Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Agreement, Seller shall immediately give notice thereof, including all relevant information, with respect thereto, to Buyer.
(b) Seller agrees to insert the substance of this clause, including this paragraph (b), in any subcontract hereunder to which a labor dispute may delay the timely performance of this Agreement. Rockwell Collins SNAP2 Corporation Agreement No. 4500601442 Date: Nov. 2,2001 SUPPORT SERVICES AGREEMENT
NOTICE TO BUYER OF LABOR DISPUTES. (1) Whenever an actual or potential labor dispute is delaying or threatening to delay the performance of this Agreement, Seller shall immediately give notice thereof to Buyer. Such notice shall include all relevant information with respect to such disputes.
(2) Seller agrees to insert the substance of Section 9(e) (Notice to Buyer of Labor Disputes) in any subcontract entered into pursuant to this Agreement as to which a labor dispute may delay the timely performance of this Agreement. The exception is that each subcontract shall provide that if its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify its next higher tier Subcontractor or Seller, as the case may be, of all relevant information with respect to such dispute.
NOTICE TO BUYER OF LABOR DISPUTES. (1) Whenever an actual or potential labor dispute is delaying or threatening to delay the performance of this Agreement, Seller shall immediately give notice thereof to Buyer. Such notice shall include all relevant information with respect to such disputes.
(2) Seller agrees to insert the substance of paragraph 9.e (Notice to Buyer of Labor Disputes) in any subcontract hereunder as to which a labor dispute may delay the timely performance of this Agreement. The exception is that each subcontract shall provide that if its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify its next higher tier Subcontractor or Seller, as the case may be, of all relevant information with respect to such dispute.
NOTICE TO BUYER OF LABOR DISPUTES. (a) Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Agreement, Seller shall immediately give notice thereof, including all relevant information with respect thereto, to Buyer.
(b) Seller agrees to insert the substance of this clause, including this paragraph (b), in any subcontract hereunder as to which a labor dispute may delay the timely performance of this Agreement; except that each such subcontract shall provide that in the event its' timely performance is delayed or threatened by delay by any actual or potential labor dispute, the subcontractor shall immediately notify the Seller of all relevant information with respect to such dispute.
