Notice to the Union At the time notice of displacement is issued, a copy of the notice shall be sent to the Union xxxxxxx.
Notice to Proceed (NTP Following the JOA and purchase order issuance, the County will issue a Notice to Proceed (NTP) that will provide the construction start date, the Work duration period, and the Substantial Completion date. The Contractor agrees to begin and complete construction within the dates specified on the NTP. The County must approve all extensions of time in writing. The County may also issue an Emergency Notice to Proceed (NTP). In the event the County requires the Contractor to respond to an immediate request for work, a Job Order will be created and an Emergency NTP will be issued. The Contractor will be required to perform the Scope of Work included with the Emergency NTP as directed by the County’s Project Manager or designee. The Detailed Scope of Work, Quotation, Subcontractor Listing, Shop Drawings and required Non Pre-priced backup documentation will be submitted upon completion of the emergency work in accordance with the Ordering Procedures detailed in Section III above.
Notice to Proceed Work shall not commence on this Project until the Director has issued a written Notice to Proceed to the Recipient. Such Notice will not be issued until the Director is assured that the Recipient has complied with the Recipient's responsibilities concerning OEPA plan approval, when applicable. A Notice to Proceed shall be required for all project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
Notice of Loss The Grantor will promptly notify the Secured Party of any loss of or material damage to any material item of Collateral or of any substantial adverse change, known to Grantor, in any material item of Collateral or the prospect of payment or performance thereof.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
Providing Notice of Breaches 8.1 If Covered Entity determines that an impermissible acquisition, access, use or disclosure of PHI for which one of Business Associate’s employees or agents was responsible constitutes a Breach as defined in 45 CFR § 164.402, and if requested by Covered Entity, Business Associate shall provide notice to the individual(s) whose PHI has been the subject of the Breach. When requested to provide notice, Business Associate shall consult with Covered Entity about the timeliness, content and method of notice, and shall receive Covered Entity’s approval concerning these elements. The cost of notice and related remedies shall be borne by Business Associate.
NOTICE TO BUYER Do not sign this agreement before you read it or if it contains any blank spaces. This is a legal instrument. All pages of this contract are binding. Read both sides of all pages before signing. You are entitled to an exact copy of the agreement, school catalog, and any other papers you may sign, and are required to sign a statement acknowledging receipt of those.
Notice of Shift Change The Co-operative agrees to give forty-eight (48) hours' notice when changing a full-time employee's shift, except in the event of an emergency (an emergency is defined as snowstorm, or flood, or breakdown of machinery, or other instances of force majeure or an unscheduled absence of an employee). Should the Co-operative fail to give forty-eight (48) hours' notice of a shift change as indicated above, each affected employee shall receive double (2) time their regular hourly rate of pay for all time worked on the new shift. Mutual agreement of employees to shift changes between each other shall not be deemed covered by this clause, (i.e. the Co- operative will not pay a penalty for this type of a shift change). Such shift changes require the prior approval of management. The Co-operative agrees that wherever possible it shall verbally advise part-time employees twenty-four (24) hours in advance when the Co-operative changes an employee's posted work schedule.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
