Developer’s Obligations 7.1.1 In consideration of the Rights hereby granted, the Developer shall pay to the Authority an annual fee of Rs. /- (Rupees only) (“Fee”) commencing from the 1st (first) anniversary of Appointed Date. The Fee is exclusive of GST and all other applicable taxes and shall be payable by the Developer at actual over and above the Fee. The Fee is payable to the Authority on or before 30 (thirty) days prior to the start of every year in advance as set out in Schedule 1 throughout the Agreement Period. During the Agreement Period the Fee shall be increased by 5% (five percent) every year over the previous year’s Fee on compounded basis.
7.1.2 The Developer should pay the Fee to the Authority notwithstanding the fact that, the development of Project Facilities is not completed within the specified period or Developer does not start the commercial operation of the Project. In other words, the Developer shall not be entitled to seek any reduction of Fee, claim, damages, compensation or any other consideration from the Authority on account of any reason.
7.1.3 Any delay in payment of the Fee shall attract an interest for the delayed period at the rate of SBI PLR plus 5% per annum on the outstanding amount, which shall be due from the date of such payment till the amount is realized by the Authority. In addition to the foregoing, any delay in payment of Fee beyond a period of 60 (sixty) days from the due date of such payment will be construed to be Material Breach under this Agreement.
Obligations During the Employment Term, Executive will perform his duties faithfully and to the best of his ability and will devote his full business efforts and time to the Company. For the duration of the Employment Term, Executive agrees not to actively engage in any other employment, occupation or consulting activity for any direct or indirect remuneration without the prior approval of the Board.
Seller Obligations Seller shall (A) arrange and pay independently for any and all necessary costs under any Generator Interconnection Agreement with the Participating Transmission Owner; (B) cause the Interconnection Customer’s Interconnection Facilities, including metering facilities, to be maintained; and (C) comply with the procedures set forth in the GIP and applicable agreements or procedures provided under the GIP in order to obtain the applicable Electric System Upgrades and (D) obtain Electric System Upgrades, as needed, in order to ensure the safe and reliable delivery of Energy from the Project up to and including quantities that can be produced utilizing all of the Contract Capacity of the Project.
Further Obligations In all matters relating to the performance of this Agreement, INTECH shall act in conformity with the Trust's Trust Instrument, bylaws and currently effective registration statements under the 1940 Act and the 1933 Act and any amendments or supplements thereto (the "Registration Statements") and with the written policies, procedures and guidelines of the Fund, and written instructions and directions of the Trustees and Janus and shall comply with the requirements of the 1940 Act, the Advisers Act, the rules thereunder, and all other applicable federal and state laws and regulations. Janus agrees to provide to INTECH copies of the Trust's Trust Instrument, bylaws, Registration Statement, written policies, procedures and guidelines and written instructions and directions of the Trustees and Janus, and any amendments or supplements to any of them at, or, if practicable, before the time such materials become effective.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Developer Obligations In accordance with applicable NYISO requirements, Developer shall maintain satisfactory operating communications with Connecting Transmission Owner and NYISO. Developer shall provide standard voice line, dedicated voice line and facsimile communications at its Large Generating Facility control room or central dispatch facility through use of either the public telephone system, or a voice communications system that does not rely on the public telephone system. Developer shall also provide the dedicated data circuit(s) necessary to provide Developer data to Connecting Transmission Owner and NYISO as set forth in Appendix D hereto. The data circuit(s) shall extend from the Large Generating Facility to the location(s) specified by Connecting Transmission Owner and NYISO. Any required maintenance of such communications equipment shall be performed by Developer. Operational communications shall be activated and maintained under, but not be limited to, the following events: system paralleling or separation, scheduled and unscheduled shutdowns, equipment clearances, and hourly and daily load data.
Conditions to the Obligations of Seller The obligations of Seller to consummate the transactions contemplated hereby to occur at the Closing are subject to the satisfaction of each of the following conditions, unless waived in whole or in part in writing by Seller:
(a) The representations and warranties of Purchaser set forth in this agreement must be true and correct in all material respects (provided that any representation or warranty contained herein that is qualified by a materiality or material adverse effect qualification shall not be so qualified for purposes of determining the existence of any breach thereof by Purchaser) as of the date of this agreement and as of the Closing Date as though made on and as of the Closing Date (except for any representation or warranty that is limited to an earlier date, in which case such representation or warranty shall have been true and correct only as of such earlier date);
(b) Purchaser must have performed in all material respects all obligations under its covenants and agreements required by this agreement to be performed by Purchaser on or before the Closing Date;
(c) Purchaser must have delivered to Seller a certificate, dated the Closing Date and signed by an authorized representative of Purchaser, as to the satisfaction of the conditions in the foregoing subsections;
(d) Purchaser must have delivered to Seller or other specified persons the documents, instruments, certificates and other items required to be delivered by Purchaser pursuant to section 5.2;
(e) There must not be in effect any temporary restraining order, preliminary or permanent injunction, stay or other order issued by any Governmental Authority preventing the consummation of the transactions contemplated hereby to occur at the Closing must be in effect; and
(f) No law must have been enacted, issued, enforced, entered, or promulgated that prohibits or makes illegal the consummation of the transactions contemplated hereby.
Breach of other obligations any Security Party commits any breach of or omits to observe any of its obligations or undertakings expressed to be assumed by it under any of the Security Documents (other than those referred to in clauses 10.1.1 and 10.1.2 above) unless such breach or omission, in the opinion of the Agent (following consultation with the Banks) is capable of remedy, in which case the same shall constitute an Event of Default if it has not been remedied within fifteen (15) days of the occurrence thereof; or
Buyer Obligations During the Delivery Term, Buyer shall arrange and be responsible for transmission service, including risk of transmission outage or curtailment, from the Delivery Point and bear all risks and costs associated with such transmission service, including, but not limited to, any transmission outages or curtailment. During the Delivery Term, Buyer shall Schedule or arrange for Scheduling Coordinator services with its Transmission Providers to receive the Product at the Delivery Point. During the Delivery Term, Buyer shall be responsible for all CAISO costs and charges, electric transmission losses and congestion from the Delivery Point.
Conditions to the Seller’s Obligations At the Closing, the Buyer shall deliver:
(i) certified copies of the resolutions duly adopted by the Buyer’s board of directors (or its equivalent governing body) authorizing the execution, delivery and performance of this Agreement and the other agreements contemplated hereby to which it is a party, and the consummation of all transactions contemplated hereby and thereby;
(ii) a certificate of an authorized officer of the Buyer in the form set forth in Exhibit E, dated as of the Closing, stating that: (i) all of the representations and warranties set forth in Article VI that are qualified as to materiality or words of similar import are true and correct in all respects, and those not so qualified are true and correct in all material respects, in each case as of the Closing (except where such representations and warranties expressly relate to an earlier date, in which case such representations and warranties shall have been true and correct as of such earlier date), and (ii) to the Buyer’s knowledge, no action or proceeding before any court or Governmental Authority is pending or threatened wherein an unfavorable judgment, decree or order which would prevent the performance of this Agreement or the consummation of any of the transactions contemplated hereby, declare unlawful the transactions contemplated by this Agreement or would reasonably be expected to cause such transactions to be rescinded;
(iii) the Estimated Purchase Price as contemplated in Section 1.02 above; and
(iv) such other documents reasonably requested by the Representative for the consummation of the transactions contemplated hereby.
