Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
OBLIGATIONS OF THE LESSEE The Lessee shall keep the premises in a clean, sanitary, neat and presentable condition. The Lessee shall be responsible for the repairs, outside of ordinary wear and tear, of any part of the Premises that do not affect the structural parts of the building or structure in which it is located or those that are generally considered as minor repair (“Minor Repairs”) including but not limited to replacing light bulbs, cleaning or repairs of windows, doors, toilets and similar appurtenances. The Lessee shall, at its sole expense restore, repair and/or rectify any damage, outside of ordinary wear and tear, to the Premises caused by the Lessee or others that the lessee permits into the Premises that are not covered or compensable by any insurance.
Obligations of the Adviser (a) The Adviser shall provide (or cause the Fund’s Custodian (as defined in Section 5 hereof, the Fund’s accountant and the Fund’s distributor) to provide) timely information to the Sub-Adviser regarding such matters as the composition of the Sub-Advised Assets, cash requirements and cash available for investment in the Sub-Advised Assets, and all other information as may be reasonably necessary for the Sub-Adviser to perform its responsibilities hereunder.
(b) The Adviser has furnished the Sub-Adviser with a copy of the prospectus and statement of additional information of the Fund and it agrees during the continuance of this Agreement to furnish the Sub-Adviser copies of any revisions or supplements thereto at, or, if practicable, before the time the revisions or supplements become effective. The Adviser agrees to furnish the Sub-Adviser with copies of any financial statements or reports made by the Fund to its shareholders, and any further materials or information that the Sub-Adviser may reasonably request to enable it to perform its functions under this Agreement.
Conditions of the Obligations of the Placement Agent The obligations of the Placement Agent hereunder shall be subject to the accuracy of the representations and warranties on the part of the Company set forth in Section 2 hereof, in each case as of the date hereof and as of each Closing Date as though then made, to the timely performance by each of the Company of its covenants and other obligations hereunder on and as of such dates, and to each of the following additional conditions:
Conditions of the Obligations of the Underwriter The obligations of the Underwriter hereunder shall be subject to the accuracy of the representations and warranties on the part of the Company set forth in Section 2 hereof, in each case as of the date hereof and as of each Closing Date as though then made, to the timely performance by each of the Company of its covenants and other obligations hereunder on and as of such dates, and to each of the following additional conditions:
Obligations of Party B 4.1 The Services provided by Party A under this Agreement shall be exclusive. During the effective term of this Agreement, without prior written consent of Party A, Party B may not enter into any agreement, orally or written, with any third party or otherwise engage such third party to provide services the same as or similar to those provided by Party A hereunder.
4.2 Party B shall provide Party A with the finalized Annual Business Plan of Party B of the next year before November 30 of each year, in order to facilitate Party A to plan for the Services, purchase necessary software and Equipment and secure necessary personnel and technical service force accordingly. In the event that Party B demands Party A to purchase any new Equipment and/or deploy additional personnel, it shall consult with Party A at least fifteen (15) days in advance in order to reach a mutual agreement between the Parties.
4.3 In order to facilitate provision of the Services by Party A, Party B shall provide Party A with relevant materials requested by Party A in an accurate and timely manner.
4.4 Party B shall pay Service Fees to Party A on time and in full amount in accordance with Article 3 of this Agreement.
4.5 Party B shall maintain its good standing and presence, actively develop its business and procure the maximization of the revenue.
4.6 The Parties hereby acknowledge that, pursuant to the terms and conditions of the Amended and Restated Equity Pledge Agreement entered into by all the registered shareholders of Party B as of the date of this Agreement (the “Existing Shareholders”) with Party A on November 3, 2017, each of the Existing Shareholders has pledged all of the equity interests in Party B held by it to Party A as security for Party B’s performance of its obligations under this Agreement.
4.7 During the term of this Agreement, Party B agrees to cooperate with Party A and Party A’s direct or indirect parent company in the audit of related party transactions and other audits, to provide relevant information and materials about Party B’s operation, business, customers, finance and employees to Party A, its parent company or its appointed auditor, and agrees that Party A’s parent company may disclose such information and materials for purpose of satisfying the regulatory requirements of the place where the securities of Party A’s parent company are listed.
Obligations of Assignee Assignee agrees to take and hold the Warrant and any shares of stock to be issued upon exercise of the rights thereunder (the “Securities”) subject to, and to be bound by, the terms and conditions set forth in the Warrant to the same extent as if Assignee were the original holder thereof.
Obligations of the Academy Trust The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.
Conditions Precedent to the Obligations of the Company The obligation hereunder of the Company to issue and sell the shares of Common Stock to the Investor incident to each Closing is subject to the satisfaction, or waiver by the Company, at or before each such Closing, of each of the conditions set forth below.
Termination of the Obligations of the Underwriters The obligations of the Underwriters to purchase the Notes on the Closing Date shall be terminable by the Representatives by written notice delivered to the Issuer and the Company if at any time on or before the Closing Date (a) trading in securities generally on the New York Stock Exchange shall have been suspended or materially limited, or there shall have been any setting of minimum prices for trading on such exchange, (b) a general moratorium on commercial banking activities in New York or Virginia shall have been declared by any of Federal, New York state or Virginia state authorities, (c) there shall have occurred any material outbreak or escalation of hostilities or other calamity or crisis, the effect of which on the financial markets of the United States is such as to make it, in the Representatives’ reasonable judgment, impracticable to market the Notes on the terms and in the manner contemplated in the Prospectus or (d) any change or any development involving a prospective change, materially and adversely affecting (i) the Trust Assets taken as a whole or (ii) the business or properties of the Issuer, the Company or the Seller occurs, which, in the Representatives’ reasonable judgment, in the case of either clause (i) or (ii), makes it impracticable or inadvisable to market the Notes on the terms and in the manner contemplated in the Prospectus. Upon such notice being given, the parties to this Agreement shall (except for the liability of the Issuer, the Company and the Seller under Section 9 and Section 10 of this Agreement and the liability of each Underwriter under Section 17 of this Agreement) be released and discharged from their respective obligations under this Agreement.