Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement. (iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person. (iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority. (v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3. (vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event. (vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement: (a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws; (b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway; (c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement; (d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement; (e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement; (f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement; (g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice; (h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times; (i) cooperate with other contractors employed by the Authority and personnel of any public authority; and (j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others. (viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works. (ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor. (x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects. (xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement. (xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices. (xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Obligations of the Customer 3.1 The Customer agrees to: (a) The Customer shall give the Company not less than 14 days prior written notice of any proposed change of ownership of the Customer and or any change in the Customer’s details (including but not limited to, changes in the customer’s name, address, contact phone/fax numbers or business practice). The Customer shall be liable for any loss incurred by the Company as a result of the Customers failure to comply with this clause. (b) Pay the Company the Price for carrying out the Works in accordance with this agreement; (c) Provide the Company with all necessary plans, specifications, services and amenities, so as to allow the Company to carry out the Works, provide access to the Location and ensure to the Company’s reasonable satisfaction that the Location remains in a state and condition that is safe for the Company and its employees and agents; (d) Ensure the Location complies with all necessary bylaws and restrictions is structurally sound (in accordance with all legislation governing safety in the workplace); (e) Not to cause any disruption or obstruction to the carrying out of any Works and to follow any reasonable instructions provided by the Company about the Works; (f) Where the Works requires co-ordination with other trades then the Customer will supply the Company with a schedule detailing all relevant information so as to allow the Company sufficient time to co-ordinate with the Customer’s other tradespersons; (g) Permit the Company to attach such reasonable signage as the Company may wish to any Works so as to identify that the Company is carrying out the Works; (h) In circumstances where it wishes to make a claim against the Company pursuant to the guarantee given in clause 13.2, exclusively permit the Company or its authorised representative to remedy or make good any defects in its Workmanship and not permit any other third party to do so. 3.2 Without prejudice to any other right or remedy of the Company, if the Customer fails to carry out or perform any of its obligations pursuant to this clause 3 (excepting clause 3.1(g)) then, in addition to any Additional Expenses Charge that may apply, the Company may charge the Customer a Services Delay Charge for each day (or part thereof) that the Company is, in its reasonable opinion, unable and/or not required to carry out or perform the Works as a result of such breach by the Customer. 3.3 Where the Customer requests any Related Work to be carried out, the Company will use its best endeavours to source suppliers and/or contractors to carry out the Related Work, but the Customer is responsible for the commissioning, controlling, and payment for such work. 3.4 The Customer acknowledges that unless otherwise agreed in writing between the Customer and the Company, the Customer shall be responsible for obtaining, paying for and maintaining in force all permits, approvals, authorisations, authorities, licences and consents of all regulatory authorities whatsoever which are or may be necessary or advisable in connection with the Works.
Obligations of the Company Whenever required under this Section 2 to effect the registration of any Registrable Securities, the Company shall, as expeditiously as reasonably possible: (a) prepare and file with the SEC a registration statement with respect to such Registrable Securities and use its commercially reasonable efforts to cause such registration statement to become effective and, upon the request of the Holders of a majority of the Registrable Securities registered thereunder, keep such registration statement effective for a period of up to one hundred twenty (120) days or, if earlier, until the distribution contemplated in the registration statement has been completed; provided, however, that (i) such one hundred twenty (120) day period shall be extended for a period of time equal to the period the Holder refrains, at the request of an underwriter of Common Stock (or other securities) of the Company, from selling any securities included in such registration, and (ii) in the case of any registration of Registrable Securities on Form S-3 that are intended to be offered on a continuous or delayed basis, subject to compliance with applicable SEC rules, such one hundred twenty (120) day period shall be extended for up to sixty (60) days, if necessary, to keep the registration statement effective until all such Registrable Securities are sold; (b) prepare and file with the SEC such amendments and supplements to such registration statement, and the prospectus used in connection with such registration statement, as may be necessary to comply with the Securities Act in order to enable the disposition of all securities covered by such registration statement; (c) furnish to the selling Holders such numbers of copies of a prospectus, including a preliminary prospectus, as required by the Securities Act, and such other documents as the Holders may reasonably request in order to facilitate their disposition of their Registrable Securities; (d) use its commercially reasonable efforts to register and qualify the securities covered by such registration statement under such other securities or blue-sky laws of such jurisdictions as shall be reasonably requested by the selling Holders; provided that the Company shall not be required to qualify to do business or to file a general consent to service of process in any such states or jurisdictions, unless the Company is already subject to service in such jurisdiction and except as may be required by the Securities Act; (e) in the event of any underwritten public offering, enter into and perform its obligations under an underwriting agreement, in usual and customary form, with the underwriter(s) of such offering; (f) use its commercially reasonable efforts to cause all such Registrable Securities covered by such registration statement to be listed on a national securities exchange or trading system and each securities exchange and trading system (if any) on which similar securities issued by the Company are then listed; (g) provide a transfer agent and registrar for all Registrable Securities registered pursuant to this Agreement and provide a CUSIP number for all such Registrable Securities, in each case not later than the effective date of such registration; (h) promptly make available for inspection by the selling Holders, any managing underwriter(s) participating in any disposition pursuant to such registration statement, and any attorney or accountant or other agent retained by any such underwriter or selected by the selling Holders, all financial and other records, pertinent corporate documents, and properties of the Company, and cause the Company’s officers, directors, employees, and independent accountants to supply all information reasonably requested by any such seller, underwriter, attorney, accountant, or agent, in each case, as necessary or advisable to verify the accuracy of the information in such registration statement and to conduct appropriate due diligence in connection therewith; (i) notify each selling Holder, promptly after the Company receives notice thereof, of the time when such registration statement has been declared effective or a supplement to any prospectus forming a part of such registration statement has been filed; and (j) after such registration statement becomes effective, notify each selling Holder of any request by the SEC that the Company amend or supplement such registration statement or prospectus. In addition, the Company shall ensure that, at all times after any registration statement covering a public offering of securities of the Company under the Securities Act shall have become effective, its xxxxxxx xxxxxxx policy shall provide that the Company’s directors may implement a trading program under Rule 10b5-1 of the Exchange Act.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Obligations of the Client 4.1. The client undertakes to inform the company in advance (meaning no later than 2 calendar days) about the dispatch of the goods, by entering the shipment into the Xxxxx.xxx software. 4.1.1. In case of non-compliance with subparagraph 3.2.1 of this agreement, the company has the right to refuse the client in accepting and placing his goods at the warehouse. 4.2. To send goods from the warehouse or to carry out other operations, the client is obliged to provide his client number (client ID) and data of the goods.
Obligations of the data exporter The data exporter agrees and warrants: (a) that the processing, including the transfer itself, of the personal data has been and will continue to be carried out in accordance with the relevant provisions of the applicable data protection law (and, where applicable, has been notified to the relevant authorities of the Member State where the data exporter is established) and does not violate the relevant provisions of that State; (b) that it has instructed and throughout the duration of the personal data processing services will instruct the data importer to process the personal data transferred only on the data exporter's behalf and in accordance with the applicable data protection law and the Clauses; (c) that the data importer will provide sufficient guarantees in respect of the technical and organisational security measures specified in Appendix 2 to this contract; (d) that after assessment of the requirements of the applicable data protection law, the security measures are appropriate to protect personal data against accidental or unlawful destruction or accidental loss, alteration, unauthorised disclosure or access, in particular where the processing involves the transmission of data over a network, and against all other unlawful forms of processing, and that these measures ensure a level of security appropriate to the risks presented by the processing and the nature of the data to be protected having regard to the state of the art and the cost of their implementation; (e) that it will ensure compliance with the security measures; (f) that, if the transfer involves special categories of data, the data subject has been informed or will be informed before, or as soon as possible after, the transfer that its data could be transmitted to a third country not providing adequate protection within the meaning of Directive 95/46/EC; (g) to forward any notification received from the data importer or any subprocessor pursuant to Clause 5(b) and Clause 8(3) to the data protection supervisory authority if the data exporter decides to continue the transfer or to lift the suspension; (h) to make available to the data subjects upon request a copy of the Clauses, with the exception of Appendix 2, and a summary description of the security measures, as well as a copy of any contract for subprocessing services which has to be made in accordance with the Clauses, unless the Clauses or the contract contain commercial information, in which case it may remove such commercial information; (i) that, in the event of subprocessing, the processing activity is carried out in accordance with Clause 11 by a subprocessor providing at least the same level of protection for the personal data and the rights of data subject as the data importer under the Clauses; and (j) that it will ensure compliance with Clause 4(a) to (i). The data importer agrees and warrants: (a) to process the personal data only on behalf of the data exporter and in compliance with its instructions and the Clauses; if it cannot provide such compliance for whatever reasons, it agrees to inform promptly the data exporter of its inability to comply, in which case the data exporter is entitled to suspend the transfer of data and/or terminate the contract; (b) that it has no reason to believe that the legislation applicable to it prevents it from fulfilling the instructions received from the data exporter and its obligations under the contract and that in the event of a change in this legislation which is likely to have a substantial adverse effect on the warranties and obligations provided by the Clauses, it will promptly notify the change to the data exporter as soon as it is aware, in which case the data exporter is entitled to suspend the transfer of data and/or terminate the contract; (c) that it has implemented the technical and organisational security measures specified in Appendix 2 before processing the personal data transferred; (d) that it will promptly notify the data exporter about: (i) any legally binding request for disclosure of the personal data by a law enforcement authority unless otherwise prohibited, such as a prohibition under criminal law to preserve the confidentiality of a law enforcement investigation, (ii) any accidental or unauthorised access, and (iii) any request received directly from the data subjects without responding to that request, unless it has been otherwise authorised to do so; (e) to deal promptly and properly with all inquiries from the data exporter relating to its processing of the personal data subject to the transfer and to abide by the advice of the supervisory authority with regard to the processing of the data transferred; (f) at the request of the data exporter to submit its data processing facilities for audit of the processing activities covered by the Clauses which shall be carried out by the data exporter or an inspection body composed of independent members and in possession of the required professional qualifications bound by a duty of confidentiality, selected by the data exporter, where applicable, in agreement with the supervisory authority; (g) to make available to the data subject upon request a copy of the Clauses, or any existing contract for subprocessing, unless the Clauses or contract contain commercial information, in which case it may remove such commercial information, with the exception of Appendix 2 which shall be replaced by a summary description of the security measures in those cases where the data subject is unable to obtain a copy from the data exporter; (h) that, in the event of subprocessing, it has previously informed the data exporter and obtained its prior written consent; (i) that the processing services by the subprocessor will be carried out in accordance with Clause 11; (j) to send promptly a copy of any subprocessor agreement it concludes under the Clauses to the data exporter.
OBLIGATIONS OF THE BUYER a. The Buyer has furnished to the Company in Exhibit B hereto such information regarding itself, the Registrable Securities held by it and the intended method of disposition of the Registrable Securities held by it as required to effect the registration of such Registrable Securities and shall execute such documents in connection with such registration as the Company may reasonably request. The Company shall notify the Buyer in writing of any other information the Company reasonably requires from the Buyer in connection with any Registration Statement hereunder. The Buyer will as promptly as practicable notify the Company of any material change in the information set forth in Exhibit B, other than changes in its ownership of the Common Stock. b. The Buyer agrees to cooperate with the Company as reasonably requested by the Company in connection with the preparation and filing of any amendments and supplements to any Registration Statement hereunder. c. The Buyer agrees that, upon receipt of any notice from the Company of the happening of any event or existence of facts of the kind described in Section 3(f) or any notice of the kind described in the first sentence of Section 3(e), the Buyer will immediately discontinue disposition of Registrable Securities pursuant to any registration statement(s) covering such Registrable Securities until the Buyer’s receipt (which may be accomplished through electronic delivery) of the copies of the filed supplemented or amended registration statement and/or prospectus contemplated by Section 3(f) or the first sentence of Section 3(e). In addition, upon receipt of any notice from the Company of the kind described in the first sentence of Section 3(e), the Buyer will immediately discontinue purchases or sales of any securities of the Company unless such purchases or sales are in compliance with applicable U.S. securities laws. Notwithstanding anything to the contrary, the Company shall cause its Transfer Agent to deliver as promptly as practicable shares of Common Stock without any restrictive legend in accordance with the terms of the Purchase Agreement in connection with any sale of Registrable Securities with respect to which the Buyer has received a Purchase Notice or VWAP Purchase Notice (both as defined in the Purchase Agreement) prior to the Buyer’s receipt of a notice from the Company of the happening of any event of the kind described in Section 3(f) or the first sentence of Section 3(e) and for which the Buyer has not yet settled.
Obligations of the Adviser (a) The Adviser shall provide (or cause the Fund’s Custodian (as defined in Section 5 hereof, the Fund’s accountant and the Fund’s distributor) to provide) timely information to the Sub-Adviser regarding such matters as the composition of the Sub-Advised Assets, cash requirements and cash available for investment in the Sub-Advised Assets, and all other information as may be reasonably necessary for the Sub-Adviser to perform its responsibilities hereunder. (b) The Adviser has furnished the Sub-Adviser with a copy of the prospectus and statement of additional information of the Fund and it agrees during the continuance of this Agreement to furnish the Sub-Adviser copies of any revisions or supplements thereto at, or, if practicable, before the time the revisions or supplements become effective. The Adviser agrees to furnish the Sub-Adviser with copies of any financial statements or reports made by the Fund to its shareholders, and any further materials or information that the Sub-Adviser may reasonably request to enable it to perform its functions under this Agreement.
Obligations of the Company Unconditional Nothing contained in this Article Thirteen or elsewhere in this Indenture or in the Securities is intended to or shall impair, as between the Company and the Holders of the Securities of any series, the obligation of the Company, which is absolute and unconditional, to pay to such Holders the principal of, premium (if any) and interest on and any Additional Amounts with respect to the Securities of such series as and when the same shall become due and payable in accordance with their terms, or is intended to or shall affect the relative rights of such Holders and creditors of the Company other than the holders of the Senior Indebtedness, nor shall anything herein or therein prevent the Trustee or any Holder from exercising all remedies otherwise permitted by applicable law upon default under this Indenture, subject to the rights, if any, under this Article Thirteen, of the holders of Senior Indebtedness in respect of cash, property or securities of the Company received upon the exercise of any such remedy. Notwithstanding anything to the contrary in this Article Thirteen or elsewhere in this Indenture or in the Securities, upon any distribution of assets of the Company referred to in this Article Thirteen, the Trustee, subject to the provisions of Sections 601 and 603, and the Holders of the Securities shall be entitled to rely upon any order or decree made by any court of competent jurisdiction in which such dissolution, winding up, liquidation or reorganization proceedings are pending, or a certificate of the liquidating trustee or agent or other Person making any distribution to the Trustee or to such Holders for the purpose of ascertaining the Persons entitled to participate in such distribution, the holders of the Senior Indebtedness and other Indebtedness of the Company, the amount thereof or payable thereon, the amount or amounts paid or distributed thereon and all other facts pertinent thereto or to this Article Thirteen so long as such court has been apprised of the provisions of, or the order, decree or certificate makes reference to, the provisions of this Article Thirteen.
OBLIGATIONS OF THE INVESTOR 4.1 At least five (5) calendar days prior to the first anticipated filing date of the Registration Statement, the Company shall notify the Investor in writing of the information the Company requires from the Investor for the Registration Statement. It shall be a condition precedent to the obligations of the Company to complete the registration pursuant to this Agreement with respect to the Registrable Securities and the Investor agrees to furnish to the Company that information regarding itself, the Registrable Securities and the intended method of disposition of the Registrable Securities as shall reasonably be required to effect the registration of such Registrable Securities and the Investor shall execute such documents in connection with such registration as the Company may reasonably request. The Investor covenants and agrees that, in connection with any sale of Registrable Securities by it pursuant to the Registration Statement, it shall comply with the “Plan of Distribution” section of the then current prospectus relating to such Registration Statement. 4.2 The Investor, by its acceptance of the Registrable Securities, agrees to cooperate with the Company as reasonably requested by the Company in connection with the preparation and filing of any Registration Statement hereunder, unless the Investor has notified the Company in writing of an election to exclude all of the Investor’s Registrable Securities from such Registration Statement. 4.3 The Investor agrees that, upon receipt of written notice from the Company of the happening of any event of the kind described in Section 3.6 or the first sentence of 3.5, the Investor will immediately discontinue disposition of Registrable Securities pursuant to any Registration Statement(s) covering such Registrable Securities until the Investor’s receipt of the copies of the supplemented or amended prospectus contemplated by Section 3.6 or the first sentence of 3.5.
