Obligations of the Licensee 5.1.1. The Licensee’s Responsibilities and Duties shall include the following, in addition to and without prejudice to other obligations under this Agreement:
a. to obtain due permits, necessary approvals, clearances and sanctions from Maha-Metro and all other competent authorities for all activities or infrastructure facilities including interior decoration, power, water supply, drainage & sewerage, telecommunication, etc.;
b. to comply and observe at all times with all Applicable Permits, approvals and Applicable Laws in the performance of its obligations under this Agreement including those being performed by any of its contractors;
c. to develop, operate and maintain the Licensed Area at all times in conformity with this Agreement;
d. to furnish Maha-Metro with the “As built” Drawings of the Licensed Space(s) within the Moratorium Period;
e. to ensure that no structural damage is caused to the existing buildings and other permanent structures at the station as a result of his activities or any of its agents, contractors etc.;
f. to take all reasonable steps to protect the environment (both on and off the property business space) and to limit damage and nuisance to people and property resulting from construction and operations, within guidelines specified as per Applicable Laws and Applicable Permits;
g. to duly supervise, monitor and control the activities of contractors, agents, etc., if any, under their respective License Agreements as may be necessary;
h. to take all responsible precautions for the prevention of accidents on or about the property business space and provide all reasonable assistance and emergency medical aid to accident victims;
i. not to permit any person, claiming through or under the Licensee, to create or place any encumbrance or security interest over whole or any part of the Licensed premises and/or other installed assets, or on any rights of the Licensee therein or under this Agreement, save and except as expressly permitted in this Agreement;
j. to keep the Licensed Space free from all unnecessary obstruction during execution of works and store the equipment or surplus materials, dispose of such equipment or surplus materials in a manner that causes least inconvenience to the Xxxxx Xxxxxxx, metro commuters or Maha-Metro’s activities.
k. at all times, to afford access to the Licensed Property Business Space to the authorised representatives of Maha-Metro, other persons duly authorised by any Governmental Agency having jurisdiction over the business of Licensed Property Business Space, to inspect the Licensed Property Business Space and to investigate any matter within their authority and upon reasonable notice; and
l. use non-combustable material in the allotted space for creation/erection/installation of any kind of furniture, fixtures and or partitions within the space. Use of combustable material within the property business space shall not be permitted under any circumstances.
m. to comply with the divestment requirements and hand over the Licensed Property Business Space to Maha-Metro upon Termination of the Agreement;
5.1.2. The Licensee shall be solely and primarily responsible to Maha-Metro for observance of all the provisions of this License Agreement on behalf of its employees and representatives and agents and any person acting under or for and on behalf of the Licensee, contractor (s) appointed for the Licensed Space as fully as if they were the acts or defaults of the Licensee, its agents or employees.
Obligations of the Parties Clause 8
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Obligations of the Processor 3.1 The Processor undertakes to carry out Data Processing exclusively on the basis of documented instructions from the Controller. If the Processor considers an instruction of the Controller to be unlawful, the Processor shall be entitled to suspend the implementation of the relevant instruction until it is confirmed or amended by the Controller.
3.2 The Processor shall be obliged to treat confidentially any personal data of which it becomes aware in connection with the Data Processing. The Processor shall impose a confidentiality obligation on all persons authorized by it to process the data, unless they are already subject to a statutory duty of confidentiality. The obligation of confidentiality and non-disclosure shall continue to apply after termination of this DPA.
3.3 The Processor shall take all necessary technical and organizational measures within the meaning of Art. 32 of the GDPR. These technical and organizational measures are data security measures to ensure a level of protection appropriate to the risk with regard to confidentiality, integrity, availability and the resilience of the systems. They shall take into account the state of the art, the costs of implementation and the nature, scope and purposes of the processing, as well as the varying likelihood and severity of the risk to the rights and freedoms of natural persons. The technical and organizational measures taken by the Processor are available at xxxxx://xxxx.xx/en/legal in the current version.
3.4 The Processor shall, where possible, support the Controller with appropriate technical and organizational measures to enable the Controller to comply with the data subject rights under Chapter III of the GDPR within the legal time limits and shall provide the Controller with the necessary information to do so upon the Controller's request, provided that the Processor has such information. If a subject submits a request to the Processor to exercise the data subject rights, the Processor shall be obliged to forward the request to the Controller if the request relates to Data Processing by the Controller.
3.5 The Processor shall support the Controller in the performance of the obligations incumbent upon the Controller pursuant to Art. 32 to 36 of the GDPR, which shall include, but not be limited to, the implementation of security measures, the notification of data protection breaches and, where applicable, the preparation of a data protection impact assessment.
3.6 The Processor shall delete the personal data of the Data Processing after the expiry of the retention periods provided for in the Main Agreement and/or without delay at the request of the Controller. If the Controller expressly requests this, the personal data shall be returned to the Party. Statutory retention periods remain unaffected by this.
3.7 The Processor is obliged to provide the Controller with information at the latter's request in order to demonstrate compliance with the obligations pursuant to Art. 28 of the GDPR. The Processor shall support the Controller in verifying the Data Processing and shall grant the Controller access to the documents and technical systems necessary for verifying the Data Processing in accordance with Section 5 of this DPA.
3.8 To the extent permitted by law, the Processor shall inform the Controller about control actions and measures taken by the supervisory authorities insofar as they relate to the Controller's Data Processing operations.
OBLIGATIONS OF THE LESSEE The Lessee shall keep the premises in a clean, sanitary, neat and presentable condition. The Lessee shall be responsible for the repairs, outside of ordinary wear and tear, of any part of the Premises that do not affect the structural parts of the building or structure in which it is located or those that are generally considered as minor repair (“Minor Repairs”) including but not limited to replacing light bulbs, cleaning or repairs of windows, doors, toilets and similar appurtenances. The Lessee shall, at its sole expense restore, repair and/or rectify any damage, outside of ordinary wear and tear, to the Premises caused by the Lessee or others that the lessee permits into the Premises that are not covered or compensable by any insurance.
Development Obligations 1. The College supports the development, production, and dissemination of copyrightable, trademarkable, patentable, and other intellectual properties by its employees.
2. It is understood that intellectual property developed by employees on or off College time, except for those materials for which the College had specifically contracted prior to June 9, 1998, shall remain the property of such employees, but shall continue to be used for the benefit of the College while the employee remains an employee of the College.
OBLIGATIONS OF THE SUPPLIER In addition to the Article 4.2 of the GPC, it is specified that:
Obligations of DOE a. In express reliance on the covenants and representations in this Compromise Agreement and to avoid further expenditure of public resources, XXX agrees to accept Respondent’s payment pursuant to section III.2.a in full satisfaction of the penalty authorized by the Act.
x. XXX agrees to issue promptly an Adopting Order adopting this Agreement.
x. XXX agrees to terminate this enforcement action with prejudice upon Respondent’s completion of its Obligations in accordance with section III.2, above. If Respondent fails to complete its Obligations in accordance with section III.2, above, DOE may notify Respondent that the Agreement is null and void and may seek the maximum penalty in accordance with 10 C.F.R. § 429.120.
Conditions to Obligations of the Parties The obligation of the Parties to effect the Generation Exchange and the other transactions contemplated by this Agreement shall be subject to the fulfillment at or prior to the Exchange Closing Date, of the following conditions:
(a) The waiting period under the HSR Act applicable to the consummation of the exchange of the Exchange Assets contemplated hereby shall have expired or been terminated;
(b) No preliminary or permanent injunction or other order or decree by any Governmental Authority which prevents the consummation of the exchange of the Exchange Assets contemplated herein shall have been issued and remain in effect (each Party agreeing to use its reasonable best efforts to have any such injunction, order or decree lifted) and no statute, rule or regulation shall have been enacted by any state or federal government or Governmental Authority prohibiting the consummation of the exchange of the Exchange Assets;
(c) The DLC Nuclear Closing as defined in the Nuclear Conveyance Agreement shall have occurred;
(d) The CAPCO Settlement Agreement shall have been executed by DLC, the FE Subsidiaries and TEC;
(e) The Support Agreement shall have been executed by FE and DLC;
(f) All consents or approvals, filings with, or notices to any Governmental Authority that are necessary for the consummation of the transactions contemplated by each of the CAPCO Settlement Agreement and the Electrical Facilities Agreement shall have been obtained or made, other than such consents, approvals, filings or notices which are not required in the ordinary course to be obtained or made prior to the consummation of the transactions thereunder or which, if not obtained or made, will not prevent the parties thereto from performing their material obligations thereunder; and
(g) There shall be no court order requiring DQE to consummate the transactions contemplated under the Agreement and Plan of Merger between DQE and Allegheny Energy, Inc.
Obligations of the data exporter The data exporter agrees and warrants:
(a) that the processing, including the transfer itself, of the personal data has been and will continue to be carried out in accordance with the relevant provisions of the applicable data protection law (and, where applicable, has been notified to the relevant authorities of the Member State where the data exporter is established) and does not violate the relevant provisions of that State;
(b) that it has instructed and throughout the duration of the personal data processing services will instruct the data importer to process the personal data transferred only on the data exporter's behalf and in accordance with the applicable data protection law and the Clauses;
(c) that the data importer will provide sufficient guarantees in respect of the technical and organisational security measures specified in Appendix 2 to this contract;
(d) that after assessment of the requirements of the applicable data protection law, the security measures are appropriate to protect personal data against accidental or unlawful destruction or accidental loss, alteration, unauthorised disclosure or access, in particular where the processing involves the transmission of data over a network, and against all other unlawful forms of processing, and that these measures ensure a level of security appropriate to the risks presented by the processing and the nature of the data to be protected having regard to the state of the art and the cost of their implementation;
(e) that it will ensure compliance with the security measures;
(f) that, if the transfer involves special categories of data, the data subject has been informed or will be informed before, or as soon as possible after, the transfer that its data could be transmitted to a third country not providing adequate protection within the meaning of Directive 95/46/EC;
(g) to forward any notification received from the data importer or any subprocessor pursuant to Clause 5(b) and Clause 8(3) to the data protection supervisory authority if the data exporter decides to continue the transfer or to lift the suspension;
(h) to make available to the data subjects upon request a copy of the Clauses, with the exception of Appendix 2, and a summary description of the security measures, as well as a copy of any contract for subprocessing services which has to be made in accordance with the Clauses, unless the Clauses or the contract contain commercial information, in which case it may remove such commercial information;
(i) that, in the event of subprocessing, the processing activity is carried out in accordance with Clause 11 by a subprocessor providing at least the same level of protection for the personal data and the rights of data subject as the data importer under the Clauses; and
(j) that it will ensure compliance with Clause 4(a) to (i). The data importer agrees and warrants:
(a) to process the personal data only on behalf of the data exporter and in compliance with its instructions and the Clauses; if it cannot provide such compliance for whatever reasons, it agrees to inform promptly the data exporter of its inability to comply, in which case the data exporter is entitled to suspend the transfer of data and/or terminate the contract;
(b) that it has no reason to believe that the legislation applicable to it prevents it from fulfilling the instructions received from the data exporter and its obligations under the contract and that in the event of a change in this legislation which is likely to have a substantial adverse effect on the warranties and obligations provided by the Clauses, it will promptly notify the change to the data exporter as soon as it is aware, in which case the data exporter is entitled to suspend the transfer of data and/or terminate the contract;
(c) that it has implemented the technical and organisational security measures specified in Appendix 2 before processing the personal data transferred;
(d) that it will promptly notify the data exporter about:
(i) any legally binding request for disclosure of the personal data by a law enforcement authority unless otherwise prohibited, such as a prohibition under criminal law to preserve the confidentiality of a law enforcement investigation,
(ii) any accidental or unauthorised access, and
(iii) any request received directly from the data subjects without responding to that request, unless it has been otherwise authorised to do so;
(e) to deal promptly and properly with all inquiries from the data exporter relating to its processing of the personal data subject to the transfer and to abide by the advice of the supervisory authority with regard to the processing of the data transferred;
(f) at the request of the data exporter to submit its data processing facilities for audit of the processing activities covered by the Clauses which shall be carried out by the data exporter or an inspection body composed of independent members and in possession of the required professional qualifications bound by a duty of confidentiality, selected by the data exporter, where applicable, in agreement with the supervisory authority;
(g) to make available to the data subject upon request a copy of the Clauses, or any existing contract for subprocessing, unless the Clauses or contract contain commercial information, in which case it may remove such commercial information, with the exception of Appendix 2 which shall be replaced by a summary description of the security measures in those cases where the data subject is unable to obtain a copy from the data exporter;
(h) that, in the event of subprocessing, it has previously informed the data exporter and obtained its prior written consent;
(i) that the processing services by the subprocessor will be carried out in accordance with Clause 11;
(j) to send promptly a copy of any subprocessor agreement it concludes under the Clauses to the data exporter.
