Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11:
(a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event;
(b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5;
(c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party.
(d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
Third Party Claims Each Notice of Claim given by Acquiror, which involves a third party (a “Third Party Claim”), shall be resolved as follows:
(a) If, within thirty (30) days after a Notice of Claim is delivered to the Seller Representative, (x) the Seller Representative produces a notice of election and (y) such notice of election includes a written acknowledgment from the Seller Representative on behalf of the Seller Guarantors and the Sellers (the “Indemnifying Persons”) that the Indemnifying Persons would be required to indemnify the Acquiror Indemnified Persons for all Damages in connection with such Third Party Claim Notice, the Indemnifying Persons shall have the right, but not the obligation to (i) take control of the defense and investigation of such Third Party Claim, (ii) employ and engage attorneys of their own choice (subject to the approval of Acquiror, such approval not to be unreasonably withheld, conditioned or delayed) to handle and defend the same, at the Indemnifying Persons’ sole cost and expense, and (iii) compromise or settle such Third Party Claim, which compromise or settlement shall be made only with the written consent of Acquiror; provided, that such consent will not be required if such settlement includes an unconditional release of the Acquiror Indemnified Persons and provides solely for payment of monetary damages for which the Acquiror Indemnified Persons will be indemnified in full. Notwithstanding the foregoing, the Indemnifying Persons shall not have the right to assume the defense of a Third Party Claim if (1) the Indemnifying Persons fail to actively and diligently conduct the defense of the Third Party Claim (after notice and reasonable opportunity to cure), (2) the Acquiror Indemnified Persons have received advice from counsel that an actual or potential conflict exists between the Acquiror Indemnified Persons and the Indemnifying Persons in connection with the defense of such Third Party Claim, (3) such Third Party Claim seeks a finding or admission of a violation of any criminal Law by an Acquiror Indemnified Person, (4) such Third Party Claim seeks an injunction or other equitable remedies in respect of an Acquiror Indemnified Person or its business, (5) such Third Party Claim relates to a Material Customer or Material Supplier, or (6) such Third Party Claim is reasonably likely to result in Damages that, taken with any other then existing claims under this Article 12, would not be not be fully indemnified hereunder.
(b) In the event that the Indemnifying Persons defend the Acquiror Indemnified Persons against a Third Party Claim, the Acquiror Indemnified Persons shall cooperate in all reasonable respects, at the Indemnifying Persons’ request, with the Indemnifying Persons and their attorneys in the investigation, trial and defense of such Third Party Claim and any appeal arising therefrom, including, if appropriate and related to such Third Party Claim, in making any counterclaim against the third party claimant, or any cross complaint against any Person, in each case, at the expense of the Indemnifying Persons. The Acquiror Indemnified Persons may, at their own sole cost and expense, monitor and further participate in (but not control) the investigation, trial and defense of such Third Party Claim and any appeal arising therefrom.
(c) Notwithstanding anything to the contrary herein, if the Indemnifying Persons do not assume such defense and investigation or does not acknowledge in writing within thirty (30) days after receipt of the Third Party Claim Notice its obligation to indemnify the Acquiror Indemnified Persons against any Damages arising from such Third Party Claim, then the Acquiror Indemnified Persons shall have the right to retain separate counsel of their choosing, defend such Third Party Claim and have the sole power to direct and control such defense (all at the cost and expense of the Indemnifying Persons if it is ultimately determined that the Acquiror Indemnified Persons are entitled to indemnification hereunder); it being understood that the Acquiror Indemnified Persons’ right to indemnification for a Third Party Claim shall not be adversely affected by assuming the defense of such Third Party Claim. Notwithstanding anything herein to the contrary, whether or not the Indemnifying Persons shall have assumed the defense of such Third Party Claim, the Acquiror Indemnified Persons shall not settle, compromise or pay such Third Party Claim for which they seeks indemnification hereunder without the prior written consent of the Indemnifying Persons, which consent shall not be unreasonably withheld, conditioned or delayed.
(d) The Acquiror Indemnified Persons and the Indemnifying Persons shall use commercially reasonable efforts to avoid production of confidential information (consistent with Law), and to cause all communications among employees, counsel and others representing any party to a Third Party Claim to be made so as to preserve any applicable attorney-client or work-product privileges.
(e) Notwithstanding anything to the contrary in this Agreement, Section 8.1(d) shall exclusively govern S Corporation Tax Proceedings.
Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
i) acts of God;
ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities;
iii) acts of war (whether declared or undeclared), invasion or civil unrest;
iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement);
v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals;
vi) earthquakes, explosions, accidents, landslides; fire;
vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality;
viii) chemical or radioactive contamination or ionizing radiation; or
ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs;
x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—
(1) the Office through which such party (which will be the Affected Party) makes and receives payments or deliveries with respect to such Transaction is prevented from performing any absolute or contingent obligation to make a payment or delivery in respect of such Transaction, from receiving a payment or delivery in respect of such Transaction or from complying with any other material provision of this Agreement relating to such Transaction (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such Office so to perform, receive or comply (or it would be impossible or impracticable for such Office so to perform, receive or comply if such payment, delivery or compliance were required on that day); or
(2) such party or any Credit Support Provider of such party (which will be the Affected Party) is prevented from performing any absolute or contingent obligation to make a payment or delivery which such party or Credit Support Provider has under any Credit Support Document relating to such Transaction, from receiving a payment or delivery under such Credit Support Document or from complying with any other material provision of such Credit Support Document (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply (or it would be impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply if such payment, delivery or compliance were required on that day), so long as the force majeure or act of state is beyond the control of such Office, such party or such Credit Support Provider, as appropriate, and such Office, party or Credit Support Provider could not, after using all reasonable efforts (which will not require such party or Credit Support Provider to incur a loss, other than immaterial, incidental expenses), overcome such prevention, impossibility or impracticability;
Additional Indemnification by the Servicer; Third Party Claims The Servicer shall indemnify the Seller, the Depositor, the Trustee and the Master Servicer (and each of their respective directors, officers, employees and agents) and the Trust Fund, and hold them harmless against any and all Costs that any such indemnified party may sustain in any way related to (i) the failure of the Servicer to perform its duties and service the Mortgage Loans in material compliance with the terms of this Agreement (including, but not limited to its obligation to provide the certification pursuant to Section 5.03(b) hereunder) or for any inaccurate or misleading information provided in the certification required pursuant to Section 5.03(b) or (ii) the failure of the Servicer to cause any event to occur or not to occur which would have occurred or would not have occurred, as applicable, if the Servicer were applying Accepted Servicing Practices under this Agreement. The Servicer shall immediately notify the Seller, the Depositor, the Master Servicer, the Trustee or any other relevant party if a claim is made by a third party with respect to this Agreement or the Mortgage Loans, assume (with the prior written consent of the indemnified party in the event of an indemnified claim) the defense of any such claim and pay all expenses in connection therewith, including counsel fees, promptly pay, discharge and satisfy any judgment or decree which may be entered against it or any other party in respect of such claim and follow any written instructions received from such indemnifying party in connection with such claim. Subject to the Servicer’s indemnification pursuant to Section 6.02, or the failure of the Servicer to service and administer the Mortgage Loans in material compliance with the terms of this Agreement, the Trust Fund shall indemnify the Servicer and hold the Servicer harmless against any and all Costs that the Servicer may sustain in connection with any legal action relating to this Agreement, the Certificates or the origination or Servicing of the Mortgage Loans by any prior owner or servicer, other than any Costs incurred by reason of the Servicer’s willful misfeasance, bad faith or negligence in the performance of duties hereunder or by reason of its reckless disregard of obligations and duties hereunder.
Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.
Additional Indemnification by the Seller; Third Party Claims (a) The Seller shall indemnify any Purchaser and its present and former directors, officers, employees and agents and the Successor Servicer and its present and former directors, officers, employees and agents, and hold such parties harmless against any and all claims, losses, damages, penalties, fines, forfeitures, legal fees and expenses (including legal fees and expenses incurred in connection with the enforcement of the Seller's indemnification obligation under this Subsection 14.01) and related costs, judgments, and any other costs, fees and expenses that such parties may sustain in any way related to the failure of the Seller to perform its duties and the Interim Servicer to service the Mortgage Loans in strict compliance with the terms of this Agreement or any Reconstitution Agreement entered into pursuant to Section 13 or any breach of any of Seller's representations, warranties and covenants set forth in this Agreement. For purposes of this clause "Purchaser" shall mean the Person then acting as the Purchaser under this Agreement and any and all Persons who previously were "Purchasers" under this Agreement and "Successor Servicer" shall mean any Person designated as the Successor Servicer pursuant to this Agreement and any and all Persons who previously were "Successor Servicers" pursuant to this Agreement.
Force Majeure Exclusions 11.4.1 Force Majeure shall not include (i) any event or circumstance which is within the reasonable control of the Parties and (ii) the following conditions, except to the extent that they are consequences of an event of Force Majeure:
a. Unavailability, late delivery, or changes in cost of the plant, machinery, equipment, materials, spare parts or consumables for the Power Project;
x. Xxxxx in the performance of any contractor, sub-contractor or their agents;
c. Non-performance resulting from normal wear and tear typically experienced in power generation materials and equipment;
d. Strikes at the facilities of the Affected Party;
e. Insufficiency of finances or funds or the agreement becoming onerous to perform; and
f. Non-performance caused by, or connected with, the Affected Party’s:
i. Negligent or intentional acts, errors or omissions;
ii. Failure to comply with an Indian Law; or
iii. Breach of, or default under this Agreement.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
