Early Occupancy If Tenant occupies the Property prior to the Commencement Date, Tenant's occupancy of the Property shall be subject to all of the provisions of this Lease. Early occupancy of the Property shall not advance the expiration date of this Lease. Tenant shall pay Base Rent and all other charges specified in this Lease for the early occupancy period.
PARTIAL OCCUPANCY OR USE 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer as required under Paragraph 11.3.1.5, the surety, and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor shall prepare and submit a list to the Architect as provided under Paragraph 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. 9.9.2 Immediately prior to partial occupancy or use, the Owner, Contractor and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. 9.9.3 Partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents.
Maximum Occupancy No more than two (2) guests per one (1) resident (who is present) are permitted in a student room/suite/apartment at any given time unless otherwise approved by the University (Residential Life).
NUMBER OF OCCUPANTS Tenant agrees that the House shall be occupied by no more than [Total Number of Occupants] persons, including no more than [Maximum Number of Children] under the age of eighteen (18) years, without the prior written consent of Landlord.
Occupancy Period a. The student may begin occupancy of their assigned room space on the dates listed in the University catalog. Failure to occupy the room by the first official day of classes each semester may result in a reassignment of the room; however, the residential student agreement will remain enforced. Students are expected to occupy their assigned room. Students who choose to vacate their assignment without being officially exempted from the agreement have abrogated their right to that space and are required to return any key(s) to the vacated assignment as directed. Failure to return key(s) as directed will result in billing for associated lock changes(s). Students remain liable for room and board charges during the life of the agreement. Students who have previously vacated and subsequently return during the agreement period will be reassigned to an available space.
Guests; Occupancy Limits No more than one person may occupy a bedroom space, except for minor children for whom the Resident is the parent or legal guardian with Owner’s consent and with consent of apartment-mates as applicable . If Resident desires to have an Overnight Guest (any person staying in the Resident’s assigned bedroom space or apartment for more than three total nights in any 30-day period), then Resident must register the Overnight Guest(s) with Owner. Resident may not have Overnight Guest(s) for more than three consecutive nights, nor for more than six total nights in any 30-day period. In the event any unregistered or unauthorized Overnight Guest(s) are identified to be in or using an apartment or bedroom space, Owner may assess against the Resident a fee of $60 per night, in addition to the right of Owner to declare Resident in material breach of this Agreement and pursue other available remedies. Although Resident may have Guests from time to time, Owner reserves the right to restrict the number of persons permitted in or about an apartment at any time in Owner’s discretion, to protect safety and the quiet enjoyment of other residents. Guests may park only in designated guest parking areas, if any, and no Guest’s vehicle may remain at the Property for more than three days.
Square Footage Buyer acknowledges that the square footage of the Property has not been measured by Seller, Seller’s broker or its auctioneer (including the square footage of the lot and home) and the square footage quoted on any marketing tools such as advertisements, brochures, MLS data, the auction website and any other information provided is based on information supplied to Seller and is deemed approximate and not guaranteed. Buyer further acknowledges that Buyer has not relied upon any such marketing tool and that such tools are not representations and/or warranties of Seller or its agent.
LEASE TYPE This Agreement shall be considered a: (check one)
Beneficial Occupancy A. The County may, at any time, and from time to time, during the performance of the Work, enter the structure for the purpose of installing any necessary Work by County labor of other contracts, and for any other purpose in connection with the installation of facilities. In doing so, the County shall endeavor not to interfere with the Contractor and the Contractor shall not interfere with other Work being done by or on behalf of the County. B. If, prior to completion and Final Acceptance of all the Work under a specific Job Order, the County takes possession of any structure (whether completed or otherwise) comprising a portion of that Project with the intent of retaining possession thereof (as distinguished from temporary possession contemplating the return to the Contractor), then, while the County is in possession of the same, the Contractor, notwithstanding its normal responsibilities, shall be relieved of liability for loss or damage to structure other than that resulting from the Contractor's fault or negligence. Such taking of possession by the County shall not relieve the Contractor from any provisions of this Contract respecting such structure, other than to the extent specified in the preceding sentence, nor constitute a final acceptance of such structure.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
