Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Minimum Payments If the Executive’s Termination Date occurs during the Agreement Term for any reason, the Executive shall be entitled to the following payments, in addition to any payments or benefits to which the Executive may be entitled under the following provisions of this Section 5 (other than this paragraph 5(a)) or the express terms of any employee benefit plan or as required by law:
Price Payment (a) ViewRay shall pay PEKO for the services (and Deliverables) that are provided to ViewRay pursuant to this Section 2 and any Work Statement, the fee specified in such Work Statement. [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential treatment has been requested with respect to the omitted portions.
Amount and Payment of Special Interest Any Special Interest that accrues on a Note pursuant to Section 7.03(A) will be payable on the same dates and in the same manner as the Stated Interest on such Note and will accrue at a rate per annum equal to one quarter of one percent (0.25%) of the principal amount thereof for the first ninety (90) days on which Special Interest accrues and, thereafter, at a rate per annum equal to one half of one percent (0.50%) of the principal amount thereof; provided, however, that in no event will Special Interest, together with any Additional Interest, accrue on any day on a Note at a combined rate per annum that exceeds one half of one percent (0.50%). For the avoidance of doubt, any Special Interest that accrues on a Note will be in addition to the Stated Interest that accrues on such Note and, subject to the proviso of the immediately preceding sentence, in addition to any Additional Interest that accrues on such Note.
Cash Payment The Employee shall make cash payments by wire transfer, certified or bank check or personal check, in each case payable to the order of the Company; the Company shall not be required to deliver certificates for Option Shares until the Company has confirmed the receipt of good and available funds in payment of the purchase price thereof.
No Duty to Collect Amounts Due From Dividend and Transfer Agent The Custodian shall not be under any duty or obligation to take action to effect collection of any amount due to the Trust from any Dividend and Transfer Agent of the Trust nor to take any action to effect payment or distribution by any Dividend and Transfer Agent of the Trust of any amount paid by the Custodian to any Dividend and Transfer Agent of the Trust in accordance with this Agreement.
Payment of Reimbursement Amount To effect the expense reimbursement provided for in this Agreement, the Fund may offset the appropriate Reimbursement Amount against the management fees, Rule 12b-1 fees and/or shareholder servicing fees payable under the Investment Management Agreement, Rule 12b-1 Plan and/or the Shareholder Servicing Agreement. Alternatively, the Reimbursement Amount shall be paid directly by IICO, IDI and/or WISC. Such offset shall be taken, or such direct payment shall be paid, two times per year within 30 days following the date of a Fund’s applicable semi-annual or annual reporting period.
