Condominiums/Planned Unit Developments If the Mortgaged Property is a condominium unit or a planned unit development (other than a de minimis planned unit development) such condominium or planned unit development project such Mortgage Loan was originated in accordance with, and the Mortgaged Property meets the guidelines set forth in the Originator's Underwriting Guidelines;
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Management of the Partnership (a) Except as otherwise expressly provided in this Agreement, the General Partner shall have full, complete and exclusive discretion to manage and control the business of the Partnership for the purposes herein stated, and shall make all decisions affecting the business and assets of the Partnership. Subject to the restrictions specifically contained in this Agreement, the powers of the General Partner shall include, without limitation, the authority to take the following actions on behalf of the Partnership:
(i) to acquire, purchase, own, operate, lease and dispose of any real property and any other property or assets including, but not limited to notes and mortgages, that the General Partner determines are necessary or appropriate or in the best interests of the business of the Partnership;
(ii) to construct buildings and make other improvements on the properties owned or leased by the Partnership;
(iii) to authorize, issue, sell, redeem or otherwise purchase any Partnership Interests or any securities (including secured and unsecured debt obligations of the Partnership, debt obligations of the Partnership convertible into any class or series of Partnership Interests, or options, rights, warrants or appreciation rights relating to any Partnership Interests) of the Partnership;
(iv) to borrow or lend money for the Partnership, issue or receive evidences of indebtedness in connection therewith, refinance, increase the amount of, modify, amend or change the terms of, or extend the time for the payment of, any such indebtedness, and secure such indebtedness by mortgage, deed of trust, pledge or other lien on the Partnership’s assets;
(v) to pay, either directly or by reimbursement, for all Administrative Expenses to third parties or to the General Partner or its Affiliates as set forth in this Agreement;
(vi) to guarantee or become a co-maker of indebtedness of the General Partner or any Subsidiary thereof, refinance, increase the amount of, modify, amend or change the terms of, or extend the time for the payment of, any such guarantee or indebtedness, and secure such guarantee or indebtedness by mortgage, deed of trust, pledge or other lien on the Partnership’s assets;
(vii) to use assets of the Partnership (including, without limitation, cash on hand) for any purpose consistent with this Agreement, including, without limitation, payment, either directly or by reimbursement, of all Administrative Expenses of the General Partner, the Partnership or any Subsidiary of either, to third parties or to the General Partner as set forth in this Agreement;
(viii) to lease all or any portion of any of the Partnership’s assets, whether or not the terms of such leases extend beyond the termination date of the Partnership and whether or not any portion of the Partnership’s assets so leased are to be occupied by the lessee, or, in turn, subleased in whole or in part to others, for such consideration and on such terms as the General Partner may determine;
(ix) to prosecute, defend, arbitrate, or compromise any and all claims or liabilities in favor of or against the Partnership, on such terms and in such manner as the General Partner may reasonably determine, and similarly to prosecute, settle or defend litigation with respect to the Partners, the Partnership, or the Partnership’s assets;
(x) to file applications, communicate, and otherwise deal with any and all governmental agencies having jurisdiction over, or in any way affecting, the Partnership’s assets or any other aspect of the Partnership business;
(xi) to make or revoke any election permitted or required of the Partnership by any taxing authority;
(xii) to maintain such insurance coverage for public liability, fire and casualty, and any and all other insurance for the protection of the Partnership, for the conservation of Partnership assets, or for any other purpose convenient or beneficial to the Partnership, in such amounts and such types, as it shall determine from time to time;
(xiii) to determine whether or not to apply any insurance proceeds for any property to the restoration of such property or to distribute the same;
(xiv) to establish one or more divisions of the Partnership, to hire and dismiss employees of the Partnership or any division of the Partnership, and to retain legal counsel, accountants, consultants, real estate brokers, and such other persons, as the General Partner may deem necessary or appropriate in connection with the Partnership business and to pay therefor such reasonable remuneration as the General Partner may deem reasonable and proper;
(xv) to retain other services of any kind or nature in connection with the Partnership business, and to pay therefor such remuneration as the General Partner may deem reasonable and proper;
(xvi) to negotiate and conclude agreements on behalf of the Partnership with respect to any of the rights, powers and authority conferred upon the General Partner;
(xvii) to maintain accurate accounting records and to file promptly all federal, state and local income tax returns on behalf of the Partnership;
(xviii) to distribute Partnership cash or other Partnership assets in accordance with this Agreement;
(xix) to form or acquire an interest in, and contribute property to, any further limited or general partnerships, limited liability companies, joint ventures or other relationships that it deems desirable (including, without limitation, the acquisition of interests in, and the contributions of property to, its Subsidiaries and any other Person in which it has an equity interest from time to time);
(xx) to establish Partnership reserves for working capital, capital expenditures, contingent liabilities, or any other valid Partnership purpose;
(xxi) to merge, consolidate or combine the Partnership with or into another Person;
(xxii) to do any and all acts and things necessary or prudent to ensure that the Partnership will not be classified as a “publicly traded partnership” for purposes of Section 7704 of the Code; and
(xxiii) to take such other action, execute, acknowledge, swear to or deliver such other documents and instruments, and perform any and all other acts that the General Partner deems necessary or appropriate for the formation, continuation and conduct of the business and affairs of the Partnership (including, without limitation, all actions consistent with allowing the General Partner at all times to qualify as a REIT unless the General Partner voluntarily terminates its REIT status) and to possess and enjoy all of the rights and powers of a general partner as provided by the Act.
(b) Except as otherwise provided herein, to the extent the duties of the General Partner require expenditures of funds to be paid to third parties, the General Partner shall not have any obligations hereunder except to the extent that partnership funds are reasonably available to it for the performance of such duties, and nothing herein contained shall be deemed to authorize or require the General Partner, in its capacity as such, to expend its individual funds for payment to third parties or to undertake any individual liability or obligation on behalf of the Partnership.
Formation of the Partnership The Partnership was formed as a limited partnership pursuant to the provisions of the Act and the Original Agreement and continued upon the terms and subject to the conditions set forth in this Agreement. Except as expressly provided herein to the contrary, the rights and obligations of the Partners and administration and termination of the Partnership shall be governed by the Act. The Partnership Interest of each Partner shall be personal property for all purposes.
CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.
POSSESSION OF THE APARTMENT PLOT
8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions.
8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex.
8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
Termination of the Partnership The Partnership shall terminate when all assets of the Partnership, after payment or due provision for all debts, liabilities and obligations of the Partnership, shall have been distributed to the Partners in the manner provided for in this Article VIII, and the Certificate shall have been canceled in the manner required by the Act.
Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
General Description of Services The A-E will be contacted by County Project Management staff on an “as-needed” basis as projects arise to provide A-E for professional services. Requirements will be discussed by both Parties and A-E shall prepare a written Scope Statement that will include the specific work to be performed, including the costs and time required to complete the project/task. Orange County Project Management staff will then review the A-E’s Scope Statement, proceed with negotiation of task costs and when satisfied, issue a Contract Task Order (“CTO”) against this Contract. The A-E shall serve as lead of a design team that may include other construction design professionals working together to ensure that the original design is carried through to the finished product, with no alterations in materials or design that would lead to safety issues or compromise the quality of the building or building component. Other team members who may be retained by the lead to support a project as a consultant may include but are not limited to landscape architects, lighting designers, data consultants, security consultants, controls engineers, commissioning consultants, traffic engineers, surveyors, estimators, special inspection, etc. The A-E shall be responsible for the preparation of comprehensive building assessments, designs, drawings, specifications, cost estimates, and reports within the scope of the CTO. In the preparation of construction drawings and specification, the A-E shall also responsible for:
A. Obtaining data by reviewing record drawings, visiting the site of the construction and by conferences with the User/Client and facility maintenance staff or by other actions as necessary to develop the design;
B. Checking of shop drawings, submittals, materials and other data submitted by the Construction Contractor for approval;
C. Furnishing consultation and advice to County to clarify the intent of the drawings and specifications and on questions that may arise during the construction of the project;
D. Space planning, programming and code compliance review and upgrades;
E. The meeting of submittal dates included in the Scope Statement of the Contract Task Order, including the work of consultants;
F. Coordination with various agencies having authority of jurisdiction for planning services, entitlement, fire life safety, CEQA, ADA, etc.;
G. Construction administration services, testing and commissioning;
H. Close out services, as-built plans, material lists, project acceptance, etc.
I. The coordination of the various elements of the design to assure compatibility of architectural, structural, electrical, mechanical/plumbing, and other design features;
J. Other services as specifically included in the Contract Task Order related to project Initiation, Planning/Design, Bid/Award, Construction and Closeout. The A-E shall restrict themselves to the Scope Statement of the Contract Task Order. Any changes in the Scope Statement shall require prior written authorization by County.
COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.
