Inspection of Goods 8.1 The Buyer shall inspect the goods upon delivery. 8.2 Where goods are damaged the Buyer shall notify the Supplier. The Buyer may reject the damaged goods and the following provisions shall apply: 8.2.1 the Supplier shall collect the damaged goods from the Buyer at the Supplier’s expense; 8.2.2 during the period between delivery of the goods to the Buyer and collection by the Supplier, the Buyer shall not be liable for any loss or further damage caused to the damaged goods; 8.2.3 all sums payable by the Buyer in relation to the damaged goods shall cease to become payable; 8.2.4 all sums paid by the Buyer in relation to the damaged goods shall be repaid by the Supplier immediately; 8.2.5 the Buyer shall be entitled to claim damages from the Supplier for any losses caused to the Buyer as a result of the goods being damaged. 8.3 Where there are shortages in the order the Buyer shall notify the Supplier and the following provisions shall apply: 8.3.1 all sums payable by the Buyer in relation to the missing goods shall cease to become payable; 8.3.2 all sums paid by the Buyer in relation to the missing goods shall be repaid by the Supplier immediately; 8.3.3 the Buyer shall be entitled to claim damages from the Supplier for any losses caused to the Buyer as a result of the shortages. 8.4 If the Buyer so requests, the Supplier shall immediately replace damaged goods or supply goods which are missing at the Supplier’s expense or the Buyer shall be entitled to cancel, without notice, the whole or any unexecuted part of the order and the rights referred to in Clause 5.2 shall apply. 8.5 Where there is an excess of goods in relation to the order the Buyer may reject the excess goods by notice in writing to the Supplier and the following provisions shall apply: 8.5.1 the Supplier shall collect the excess goods from the Buyer at the Supplier’s expense; 8.5.2 during the period between delivery of the goods and collection by the Supplier, the Buyer shall not be liable for any loss or damage caused to the excess goods; 8.5.3 no sum shall be due to the Supplier for the excess goods and in the event that sums are paid to the Supplier for the excess goods, the Supplier shall repay such sums to the Buyer immediately. 8.6 The Buyer may accept excess goods by notifying the Supplier of such acceptance and the price of the excess goods shall be payable by the Buyer. 8.7 The Supplier shall repair or replace free of charge, goods damaged or lost in transit upon receiving notice to that effect from the Buyer. 8.8 The Buyer’s signature on any delivery note of the Supplier is evidence of the number of packages received only and not evidence of the correct quantity of goods received or that the goods are in a good condition or of the correct quality.
INSPECTION AND REJECTION 8.1 Purchaser shall have the right to inspect and test Products at any time prior to shipment, and within a reasonable time after delivery to the Purchaser’s Destination. Products not inspected within a reasonable time after delivery shall be deemed accepted by Purchaser. The payment for Products shall in no way impair the right of Purchaser to reject nonconforming Products, or to avail itself of any other remedies to which it may be entitled. 8.2 If any of the Products are found at any time to be defective in material or workmanship, damaged, or otherwise not in conformity with the requirements of this Agreement or any applicable Purchase Order, as its exclusive remedy, Purchaser may at its option and at Vendor’s sole cost and expense, elect either to (i) return any damaged, non-conforming or defective Products to Vendor for correction or replacement, or (ii) require Vendor to inspect the Products and remove or replace damaged, non-conforming or defective Products with conforming Products. If Purchaser elects option (ii) in the preceding sentence and Vendor fails promptly to make the necessary inspection, removal and replacement, Purchaser, at its option, may inspect the Products and Vendor shall bear the cost thereof. Payment by Purchaser of any invoice shall not constitute acceptance of the Products covered by such invoice, and acceptance by Purchaser shall not relieve Vendor of its warranties or other obligations under this Agreement. 8.3 The provisions of this Article shall survive the expiration or termination of this Agreement.
Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (JUN 2020) (41 U.S.C. 3509). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Payments by Wire-Transfer All payments under this Single Family Shared-Loss Agreement shall be made by wire-transfer in accordance with the wire-transfer instructions on Exhibit 4.
Inspection and Rejection of Nonconforming Goods The Buyer has the right to inspect the Goods on or after the Delivery Date. Buyer, at its sole option, may inspect all or a sample of the Goods, and may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective. If Buyer rejects any portion of the Goods, Buyer has the right, effective upon written notice to Seller, to: (a) rescind the Order in its entirety; (b) accept the Goods at a reasonably reduced price; or (c) reject the Goods and require replacement of the rejected Goods. If Buyer requires replacement of the Goods, Seller shall, at its expense, promptly replace the nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective goods and the delivery of replacement Goods. If Seller fails to timely deliver replacement Goods, Buyer may replace them with goods from a third party and charge Seller the cost thereof and terminate this Order for cause pursuant to Section 19. Any inspection or other action by Buyer under this Section shall not reduce or otherwise affect Seller's obligations under the Order, and Buyer shall have the right to conduct further inspections after Seller has carried out its remedial actions.
Order of Completion of Transactions The transactions provided for in Article II and Article III of this Agreement shall be completed immediately following the Effective Time in the following order: first, the transactions provided for in Article II shall be completed in the order set forth therein; and second, following the completion of the transactions provided for in Article II, the transactions provided for in Article III, if they occur, shall be completed.
Order Confirmation All TIPS Member Agreement purchase orders are approved daily by TIPS and sent to vendor. The vendor should confirm receipt of orders to the TIPS Member (customer) within 3 business days. • Vendor custom website for TIPS: If Vendor is hosting a custom TIPS website, updated pricing when effective. TIPS shall be notified when prices change in accordance with the award.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
