Organization of completion acceptance Sample Clauses

Open Split View

Download

Share

Cite

Organization of completion acceptance. The Employer shall organize the completion acceptance in time according to the contract.

Sample 1

Save

Copy

Related to Organization of completion acceptance

• Procedure for Acceptance If Tenant wishes to exercise Tenant’s right of first refusal with respect to the space described in the First Refusal Notice, then within five (5) business days after delivery of the First Refusal Notice to Tenant (“Election Date”), Tenant shall deliver notice to Landlord of Tenant’s exercise of its right of first refusal with respect to the entire space described in the First Refusal Notice and on the First Refusal Economic Terms contained therein. Subject to the remaining provisions of this Section 1.4.2, if Tenant does not exercise its right of first refusal within the five (5) business day period (on all of the First Refusal Economic Terms), then Landlord shall be free to lease the space described in the First Refusal Notice to anyone to whom Landlord desires on any terms Landlord desires and Tenant’s right of first refusal with respect to the space identified in the First Refusal notice shall thereupon automatically terminate; provided, however, that if Landlord intends to enter into a lease upon First Refusal Economic Terms which are, in the aggregate, materially more favorable to a prospective tenant than those First Refusal Economic Terms proposed by Landlord in the First Refusal Notice to Tenant, then Landlord shall first deliver written notice to Tenant (“Second Chance Notice”) providing Tenant with the opportunity to lease the First Refusal Space on such more favorable First Refusal Economic Terms. For purposes hereof, First Refusal Economic Terms shall be materially more favorable to a third party if such First Refusal Economic Terms reflect a net effective rental rate (including any rent abatement and Tenant Improvement costs/allowance and any other economic concessions) less than ninety-five percent (95%) of the net effective rental rate for such First Refusal Space as those proposed by Landlord in the First Refusal Notice to Tenant. Tenant’s failure to elect to lease the First Refusal Space upon such more favorable First Refusal Economic Terms by written notice to Landlord within five (5) business days after Tenant’s receipt of such Second Chance Notice from Landlord shall be deemed to constitute Tenant’s election not to lease such space upon such more favorable First Refusal Economic Terms, in which case Landlord shall be entitled to lease such space to any third (3rd) party on terms not materially more favorable to the third (3rd) party than those set forth in the Second Chance Notice; provided, however, that for purposes of the Second Chance Notice, First Refusal Economic Terms shall be materially more favorable to a third party if such First Refusal Economic Terms reflect a net effective rental rate (including any rent abatement and Tenant Improvement costs/allowance and any other economic concessions) less than ninety-eight percent (98%) of the net effective rental rate for such First Refusal Space as those proposed by Landlord in the First Refusal Notice to Tenant. If Landlord does lease such First Refusal Space to a third (3rd) party tenant pursuant to the terms and conditions of this Section 1.4.2, Tenant shall have no further right to lease such First Refusal Space. If Landlord does not enter into a lease or leases all of the First Refusal Space identified by Landlord in such First Refusal Notice within three (3) months after the date Landlord first delivered such First Refusal Notice to Tenant, then Landlord shall submit to Tenant a new First Refusal Notice with respect to any such unleased First Refusal Space before Landlord may lease such space to another party, provided that no existing Superior Right holder wishes to lease such space in accordance with its Superior Rights in which event the foregoing procedures shall again apply following Tenant’s receipt of such new First Refusal Notice. Notwithstanding anything to the contrary contained herein, Tenant must elect to exercise its right of first refusal, if at all, with respect to all of the space comprising the First Refusal Space offered by Landlord to Tenant at any particular time, and Tenant may not elect to lease only a portion thereof or object to any of the First Refusal Economic Terms.

• Prompt Acceptance of Agreement The Restricted Share Unit grant evidenced by this Agreement shall, at the discretion of the Administrator, be forfeited if this Agreement is not manually executed and returned to the Company, or electronically executed by Awardee by indicating Awardee’s acceptance of this Agreement in accordance with the acceptance procedures set forth on the Company’s third-party equity plan administrator’s web site, within 90 days of the Grant Date.

• CERTIFICATE OF ACCEPTANCE Upon successful completion of the Technical Acceptance Process, the Buyer will, on or before the Delivery Date, sign and deliver to the Seller a certificate of acceptance in respect of the Aircraft in the form of Exhibit D (the “Certificate of Acceptance”).

• Final Acceptance 1. Within thirty (30) days of the date of receipt by Purchaser and Independent Engineer of the Final Commissioning Report, the Purchaser shall issue a Certificate of Final Acceptance or reject such Report. If the Purchaser neither issues a Certificate of Final Acceptance nor rejects such Report within such thirty (30) day period, then the Date of Final Acceptance of the System shall be deemed to be the date such Final Commissioning Report was received by the Purchaser.

• Completion of a Utilisation Request (a) Each Utilisation Request is irrevocable and will not be regarded as having been duly completed unless:

• Authorization; Acceptance of Trusts and Duties Each of the Class A Trustee and the Class B Trustee hereby designates and appoints the Subordination Agent as the agent and trustee of such Trustee under the applicable Liquidity Facility and authorizes the Subordination Agent to enter into the applicable Liquidity Facility as agent and trustee for such Trustee. Each of the Liquidity Providers and the Trustees hereby designates and appoints the Subordination Agent as the Subordination Agent under this Agreement. WTC hereby accepts the duties hereby created and applicable to it as the Subordination Agent and agrees to perform the same but only upon the terms of this Agreement and agrees to receive and disburse all monies received by it in accordance with the terms hereof. The Subordination Agent shall not be answerable or accountable under any circumstances, except (a) for its own willful misconduct or gross negligence (or ordinary negligence in the handling of funds), (b) as provided in Sections 2.2 or 5.3 hereof and (c) for liabilities that may result from the material inaccuracy of any representation or warranty of the Subordination Agent made in its individual capacity in any Operative Agreement. The Subordination Agent shall not be liable for any error of judgment made in good faith by a Responsible Officer of the Subordination Agent, unless it is proved that the Subordination Agent was negligent in ascertaining the pertinent facts.

• Conditions Subsequent to the Initial Extension of Credit The obligation of the Lender Group (or any member thereof) to continue to make Advances (or otherwise extend credit hereunder) is subject to the fulfillment, on or before the date applicable thereto, of each of the conditions subsequent set forth below (the failure by Borrowers to so perform or cause to be performed constituting an Event of Default):

• Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.

• Term SOFR Conforming Changes In connection with the use or administration of Term SOFR, the Administrative Agent will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Loan Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Loan Document. The Administrative Agent will promptly notify the Borrower and the Lenders of the effectiveness of any Conforming Changes in connection with the use or administration of Term SOFR.

• Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.