Payment Does Not Imply Acceptance of Work. The granting of any payment by the AOC, or the receipt thereof by the Contractor, shall in no way lessen the liability of the Contractor to correct unsatisfactory work in connection with this Agreement.
Appears in 76 contracts
Samples: Construction Manager at Risk, Construction Contract, Design Assist Agreement
Payment Does Not Imply Acceptance of Work. The granting of any payment by the AOC, or the receipt thereof by the Contractor, shall in no way lessen the liability of the Contractor to correct unsatisfactory work in connection with the Services. Services that do not conform to the requirements of this AgreementAgreement may be rejected by the AOC and in such case the Contractor must correct the delivery of Services without delay.
Appears in 5 contracts
Samples: Standard Agreement, Standard Agreement, Standard Agreement
Payment Does Not Imply Acceptance of Work. The granting of any payment by the AOC, or the receipt thereof by the Contractor, shall in no way lessen alter the liability obligation of Contractor to remedy unsatisfactory performance of the Services. Services that do not conform to the requirements of this Agreement, in the AOC’s judgment, may be rejected by the AOC. In such case, Contractor must remedy the unsatisfactory performance without delay to correct unsatisfactory work in connection bring it into conformance with this Agreement.
Appears in 2 contracts
Samples: Contract Terms and Conditions, Contract Terms and Conditions
Payment Does Not Imply Acceptance of Work. The granting of any payment Payment by the AOC, or the receipt thereof by the Contractor, shall in no way lessen the liability of the Contractor to correct unsatisfactory work Work in connection with this Agreement.
Appears in 1 contract
