Common use of Payment Does Not Imply Acceptance of Work Clause in Contracts

Payment Does Not Imply Acceptance of Work. Court’s payment will not relieve Contractor from its obligation to replace unsatisfactory Work, even if the unsatisfactory character of such Work may have been apparent or detected at the time such payment was made. Work, Data, or components that do not conform to requirements of this Agreement will be rejected, and will be replaced by Contractor, without delay or additional cost to Court.

Payment Does Not Imply Acceptance of Work. The Court’s payment will not relieve Contractor from its obligation to replace unsatisfactory Work, even if the unsatisfactory character of such Work may have been apparent or detected at the time such payment was made. Work, Data, or components that do not conform to the requirements of this the Agreement will be rejected, and will be replaced by Contractor, without delay or additional cost to the Court.

Payment Does Not Imply Acceptance of Work. Court’s payment will not relieve Contractor from its obligation to replace unsatisfactory Workwork, even if the unsatisfactory character of such Work work may have been apparent or detected at the time such payment was made. WorkServices, Datawork, data, or components that do not conform to requirements of this Agreement will be rejected, and will be replaced by Contractor, Contractor without delay or additional cost to Court.