Payment of Costs of Recovery of Schedule Delays. Costs attributable to recovery of schedule delays, after execution of the GMP Change Order, may be paid from the Construction Contingency.
Payment of Costs of Recovery of Schedule Delays Sample Clauses
Related to Payment of Costs of Recovery of Schedule Delays
Recovery of Schedule Delays If the Design Professional determines that the Project is one week or more behind schedule, per the approved Overall Project Schedule, the Design Professional shall so notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
Recovery of Costs If any legal action or other proceeding is brought for the enforcement of this Agreement, or because of an alleged dispute, breach, default or misrepresentation in connection with any of the provisions of this Agreement, the successful or prevailing party shall be entitled to recover reasonable attorneys’ fees and other costs incurred in that action or proceeding (and any additional proceeding for the enforcement of a judgment) in addition to any other relief to which it or they may be entitled.
Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
Reimbursement of Costs City may reimburse Consultant’s out-of-pocket costs incurred by Consultant in the performance of the Required Services if negotiated in advance and included in Exhibit A. Unless specifically provided in Exhibit A, Consultant shall be responsible for any and all out-of-pocket costs incurred by Consultant in the performance of the Required Services.
Recovery of Sums Due Wherever any sum of money is recoverable from or payable by the Contractor, the Authority may deduct that sum from any sum due, or which at any later time may become due to the Contractor under the Contract or under any other agreement with the Authority.
