Payment of Project Costs Mechanics Liens
Payment of Project Costs Mechanics Liens Sample Clauses
Related to Payment of Project Costs Mechanics Liens
Title to Properties; Priority of Liens Each Borrower and Subsidiary has good and marketable title to (or valid leasehold interests in) all of its Real Estate, and good title to all of its personal Property, including all Property reflected in any financial statements delivered to Agent or Lenders, in each case free of Liens except Permitted Liens. Each Borrower and Subsidiary has paid and discharged all lawful claims that, if unpaid, could become a Lien on its Properties, other than Permitted Liens. All Liens of Agent in the Collateral are duly perfected, first priority Liens, subject only to Permitted Liens that are expressly allowed to have priority over Agent’s Liens.
Construction Liens (a) Tenant will not suffer or permit any contractor’s, subcontractor’s or supplier’s lien (a “Construction Lien”) to be filed against the Premises or any part thereof by reason of work, labor services or materials supplied or claimed to have been supplied to Tenant; and if any Construction Lien shall at any time be filed against the Premises or any part thereof, Tenant, within ten (10) days after notice of the filing thereof, shall cause it to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If Tenant shall fail to cause such Construction Lien to be discharged within the period aforesaid, then in addition to any other right or remedy, Landlord may, but shall not be obligated to, discharge it either by paying the amount claimed to be due or by procuring the discharge of such lien by deposit or by bonding proceedings. Any amount so paid by Xxxxxxxx, plus all of Landlord’s costs and expenses associated therewith (including, without limitation, reasonable legal fees), shall constitute Additional Rent payable by Tenant under this Lease and shall be paid by Tenant to Landlord on demand with interest from the date of advance by Landlord at the Default Rate.
Title to Properties; Possession Under Leases (a) Such Borrower and each of its Subsidiaries have good and marketable title to, or valid leasehold interests in, all its material properties and assets, except for minor defects in title that do not materially interfere with its ability to conduct its business as currently conducted or to utilize such properties and assets for their intended purposes.
Collateral Protection Expenses Preservation of Collateral (a) If an Event of Default shall have occurred and be continuing, the Agent may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral, make repairs thereto and pay any necessary filing fees. Each Grantor agrees to reimburse the Agent on demand for any and all expenditures so made. The Agent shall have no obligation to any Grantor to make any such expenditures, nor shall the making thereof relieve any Grantor of any default.
Completion of Improvements Landlord, through its general contractor (“Contractor”), shall furnish and install within the Premises those items of general design, engineering and construction, shown on the final plans and specifications approved by Landlord and Tenant pursuant to the Schedule of Approvals below, in compliance with all applicable laws, ordinances, codes, rules and regulations and matters of record, and complete any construction required in the Common Areas of the Building when such construction is required by or arises out of completion of such work (collectively the “Improvements”). The contractor constructing the Improvements in the Premises shall be selected pursuant to a procedure whereby the final Plans and Specifications (as such term is defined in this Exhibit B) are submitted to Xxxxxxx Xxxxxx Builders, Inc. (“XXX”) and Pinnacle Contracting Corporation (collectively, the “Approved Contractors”), who shall be requested to each submit to Landlord and to Tenant a sealed contract bid using such forms reasonably acceptable to Landlord in order to provide an “apples to apples” bidding process. The sealed bids shall be delivered to Tenant and Landlord and opened jointly by Landlord and Xxxxxx. Tenant, in Tenant’s sole and absolute discretion, shall select the Contractor from the two Approved Contractors (regardless of which has the lower bid). Each bid from the contractors shall specify any allowances for exclusions and shall further provide that said bids are without overtime premiums or bonuses necessary to complete the Improvements in accordance with the terms hereof. The architect engaged by Xxxxxx to prepare the Space Plan and Plans and Specifications and related design work for the Improvements shall be Xxxxxxx (the “Architect”). Landlord shall disburse amounts of the Allowance (up to the maximum specified below) to Architect within thirty (30) days after receipt of paid invoices from Architect or Tenant for Architect’s services; provided, however, notwithstanding the foregoing, Landlord shall pay $[***] for the Architect’s preparation of the Space Plan (as evidenced by the Architect’s invoice number 68045 dated October 15, 2010), at Landlord’s sole cost and expense (and without using the Allowance or any portion thereof). The definition of Improvements shall include all costs associated with completing the Improvements, including but not limited to, fees payable to Xxxxxxx, space planning, design, architectural, and engineering fees, contracting, labor and material costs, municipal fees, plan check and permit costs, and document development and/or reproduction, and all costs and expenses for any construction manager(s) engaged by Xxxxxx (provided such soft costs for architectural and engineering services charged against the Allowance shall not exceed $[***] per square feet of Usable Area in the Premises) at Tenant’s sole option. The Space Plan and the Plans and Specifications (each as defined in Section 3 of this Exhibit B) shall be subject to Landlord’s prior review and approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord’s approval of any iteration of a Space Plan or Plans and Specifications shall be deemed granted unless Landlord provides a reasonable disapproval or approval to Tenant prior to the sixth (6th) business day after Landlord’s receipt of the Space Plan or Plans and Specifications. Without limiting Landlord’s discretion to reasonably withhold its approval, Tenant agrees that it shall be reasonable for Landlord to withhold its approval of any aspect of Tenant’s Space Plan or Plans and Specifications (or, in either case, any proposed changes thereto) which (i) adversely affect Building systems, the structure of the Building or the safety of the Building and/or its occupants, (ii) would violate any governmental laws, rules or ordinances; (iii) would require any changes that adversely impact the base, shell and core of the Building, and/or (iv) are inconsistent with the standards of first class office buildings in the vicinity of the Building, as reasonably determined by Landlord and the Contractor. Landlord shall provide a written statement of any disapproval of any Space Plan or Plans and Specifications stating the reasons for Xxxxxxxx’s disapproval. Tenant acknowledges and agrees that any change in the scope of work or details of construction after Xxxxxx’s and Landlord’s approval of the Plans and Specifications shall constitute a “Change Order”, the costs of which may be charged against any available amounts of the Allowance under this Exhibit B. To the extent the Change Order delays construction of the Improvements, the same shall be a Tenant Delay. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION.
Priority of Liens; Title to Properties The security interests and liens granted to Lender under this Agreement and the other Financing Agreements constitute valid and perfected first priority liens and security interests in and upon the Collateral subject only to the liens indicated on Schedule 8.4 hereto and the other liens permitted under Section 9.8 hereof. Borrower has good and marketable title to all of its properties and assets subject to no liens, mortgages, pledges, security interests, encumbrances or charges of any kind, except those granted to Lender and such others as are specifically listed on Schedule 8.4 hereto or permitted under Section 9.8 hereof.
Condition of Improvements The Improvements and the Tangible Personal Property (including but not limited to the mechanical systems, plumbing, electrical, wiring, appliances, fixtures, heating, air conditioning and ventilating equipment, elevators, boilers, equipment, roofs, structural members and furnaces) shall be in the same condition at Closing as they are as of the date hereof, reasonable wear and tear excepted. Prior to Closing, the Contributor shall not have diminished the quality or quantity of maintenance and upkeep services heretofore provided to the Real Property and the Tangible Personal Property and the Contributor shall not have diminished the Inventory. The Contributor shall not have removed or caused or permitted to be removed any part or portion of the Real Property or the Tangible Personal Property unless the same is replaced, prior to Closing, with similar items of at least equal quality and acceptable to the Acquiror.
Maintenance of Properties and Leases Each Loan Party shall, and shall cause each of its Subsidiaries to, maintain in good repair, working order and condition (ordinary wear and tear excepted) in accordance with the general practice of other businesses of similar character and size, all of those properties useful or necessary to its business, and from time to time, such Loan Party will make or cause to be made all appropriate repairs, renewals or replacements thereof.
Enforcement and preservation costs The Borrower shall, within three Business Days of demand, pay to each Administrative Party and each other Secured Party the amount of all out-of-pocket costs and expenses (including legal fees) incurred by it in connection with the enforcement of or the preservation of any rights under any Finance Document and the Transaction Security and any proceedings instituted by or against the Security Agent or the U.S. Collateral Agent as a consequence of taking or holding the Transaction Security or enforcing these rights.
Mechanic’s Liens Tenant shall pay or cause to be paid all costs and charges for work (a) done by Tenant or caused to be done by Tenant, in or to the Premises, and (b) for all materials furnished for or in connection with such work. Tenant shall indemnify Landlord against and hold Landlord, the Premises, and the Project free, clear, and harmless of and from all mechanics’ liens and claims of liens, and all other liabilities, liens, claims, and demands on account of such work by or on behalf of Tenant, other than work performed by Landlord pursuant to this Lease. If any such lien, at any time, is filed against the Premises or any part of the Project, Tenant shall cause such lien to be discharged of record within ten (10) days after the filing of such lien, except that if Tenant desires to contest such lien, it shall deliver to Landlord, within such 10-day period, at least one hundred fifty percent (150%) of the amount of the claim, plus estimated costs and interest, by cashier’s check or certified funds which shall be held by Landlord as security to insure payment of the lien and to prevent any sale of the Project by foreclosure or otherwise by reason of such lien. If a final judgment establishing the validity or existence of a lien for any amount is entered, Tenant shall pay and satisfy the same at once. If Tenant fails to pay any charge, cost or expense for which a mechanics’ lien has been filed, and has not given Landlord security as described above, Landlord may, at its option, pay such charge and related costs and interest, and the amount so paid, together with reasonable attorneys’ fees incurred in connection with such lien, shall be immediately due from Tenant to Landlord as Additional Rent. Nothing contained in this Lease will be deemed the consent or agreement of Landlord to subject Landlord’s interest in the Project to liability under any mechanics’ or other lien law. If Tenant receives written notice that a lien has been or is about to be filed against the Premises or the Project, or that any action affecting title to the Project has been commenced on account of work done by or for or materials furnished to or for Tenant, it shall immediately give Landlord written notice of such notice. At least fifteen (15) days prior to the commencement of any work (including but not limited to any maintenance, repairs, alterations, additions, improvements, or installations) in or to the Premises, by or for Tenant, Tenant shall give Landlord (i) written notice of the proposed work and the names and addresses of the persons supplying labor and materials for the proposed work and (ii) two copies of Tenant’s plans and specifications for such work.
