Disbursements to Contractors to Pay Costs of the Project The Recipient shall require that as work on the Project and as specified in its contract is performed a Contractor shall promptly submit a detailed project specific invoice to the Project Manager. Within three (3) Business Days following receipt of such invoice from a Contractor, the Project Manager shall review the invoice and, if found to be accurate, shall so certify in writing, forwarding such certification together with a copy of the invoice to the Chief Fiscal Officer. Within five (5) Business Days following receipt of such invoice and certification from the Project Manager, the Chief Fiscal Officer shall conduct such reviews as he considers appropriate and, if he approves such invoice, shall submit to the Director a Disbursement Request together with the information and certifications required by this Section 6(b). The dollar amount set forth in the Disbursement Request shall be calculated based on the Participation Percentage as set forth originally in Appendix D of this Agreement or as may be adjusted from time to time to account for changed conditions in the project financing scheme. Within five (5) Business Days following receipt of the Disbursement Request and all required information and certifications, the Director shall, if such items are deemed by the Director to be accurate and completed, initiate a voucher in accordance with applicable State requirements for the payment of the amount set forth in the Disbursement Request. Upon receipt of a warrant from the Auditor of State drawn in connection with a voucher initiated in accordance with the terms of the preceding sentence, the Director shall forward it by regular first class United States mail or electronic funds transfer, to the contractor or other authorized recipient designated in the Disbursement Request. Prior to any disbursement from the Fund, the following documents shall be submitted to the Director by the Recipient:
(i) If the request is for disbursement to a Contractor, an invoice submitted to the Recipient by the Contractor which invoice requests payment of such sums in connection with its performance of the Project;
(ii) If the request is for disbursement to the Recipient pursuant to Paragraph (A)(4)(b) of Rule 164-1-22 of the Administrative Code, a xxxx of sale, paid invoice or other evidence satisfactory to the Director that payment of such sums has been made by the Recipient in connection with the portion of the Project for which payment is requested;
(iii) The Project Manager's certification pursuant to Section 6(b) of this Agreement;
(iv) The Disbursement Request Form and Certification in the form set forth as Appendix E of this Agreement properly executed by the Chief Fiscal Officer and the Chief Executive Officer; and
(v) Such other certificates, documents and other information as the Director may reasonably require. If the Director finds that the documents are in compliance with the requirements of this Agreement, the Director is authorized and directed to cause the disbursement of moneys from the Fund for payment of the identified Project costs. A copy of all such documents submitted to the Director shall be retained by the Director. The Recipient represents that the Project was initially constructed, installed or acquired by the Recipient no earlier than the execution date of this Agreement.
Payments to the Owner Allstate Life shall withdraw from the Funding Account and pay to or at the direction of the Owner amounts in accordance with the terms set forth in the Annex hereto. All payments made by Allstate Life to the Owner hereunder shall be paid in cash, in same-day, freely transferable funds on the date of payment to such account as has been specified for such purpose in writing by the Owner to Allstate Life.
Payment of Project Activities County will reimburse Subrecipient for eligible project-related costs only. Subrecipient shall submit requests for reimbursement to County on a monthly basis beginning on August 1, 2021, and must provide adequate documentation as required by County in accordance with the OC Community Resources Contract Reimbursement Policy, as set forth in Exhibit 1, attached hereto and incorporated herein by reference. In addition, Subrecipient will provide a progress Grantee Performance Report (“GPR Information Form”) for the time period covered, as prescribed by County. Failure to provide any of the required documentation and reporting will cause County to withhold all or a portion of a request for reimbursement, or return the entire reimbursement package to Subrecipient, until such documentation and reporting has been received and approved by County.
Payments to the Distributor In consideration of the payments made by the Fund to the Distributor under this Plan, the Distributor shall provide administrative support services and distribution assistance services to the Fund. Such services include distribution assistance and administrative support services rendered in connection with Shares (1) sold in purchase transactions, (2) issued in exchange for shares of another investment company for which the Distributor serves as distributor or sub-distributor, or (3) issued pursuant to a plan of reorganization to which the Fund is a party. If the Board believes that the Distributor may not be rendering appropriate distribution assistance or administrative support services in connection with the sale of Shares, then the Distributor, at the request of the Board, shall provide the Board with a written report or other information to verify that the Distributor is providing appropriate services in this regard. For such services, the Fund will make the following payments to the Distributor:
Payments to Owner Section 4.01 Remittances...................................................29 Section 4.02 Statements to Owner...........................................29 Section 4.03 Monthly Advances by Servicer..................................30 Section 4.04 Due Dates Other Than the First of the Month...................30 ARTICLE V
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
Payments to the Company Except as provided in Section 3 hereof, after the Trust has become irrevocable, the Company shall have no right or power to direct the Trustee to return to the Company or to divert to others any of the Trust assets before all payments of benefits have been made to Plan participants and their beneficiaries pursuant to the terms of the Plans.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Certain Reimbursements to the Servicer The Servicer will be entitled to be reimbursed from amounts on deposit in the Collection Account with respect to a Collection Period for amounts previously deposited in the Collection Account but later determined by the Servicer to have resulted from mistaken deposits or postings or checks returned for insufficient funds. The amount to be reimbursed hereunder shall be paid to the Servicer on the related Distribution Date pursuant to Section 5.7(a)(i) upon certification by the Servicer of such amounts and the provision of such information to the Trust Collateral Agent. The Servicer will additionally be entitled to receive from amounts on deposit in the Collection Account with respect to a Collection Period any amounts paid by Obligors that were deposited in the Lockbox Account but that do not relate to (i) principal and interest payments due on the Receivables and (ii) any fees or expenses related to extensions due on the Receivables.
Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items:
9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.
