Performance Guarantee 9.4.1 The Concessionaire shall, for the performance of its obligations hereunder during the Concession Period, provide to the Authority no later than [90] days prior to expiry of the Performance Security, an irrevocable and unconditional guarantee from a Bank for a sum equivalent to Rs. ***** crore (Rupees ***** crore)7 in the form set forth in Schedule-FF (the “Performance Guarantee”). Until such time the Performance Guarantee is provided by the Concessionaire pursuant hereto and the same comes into effect, notwithstanding anything contained in clause 9.3 the Performance Security shall remain in force and effect, and upon such provision of the Performance Guarantee pursuant hereto, the Authority shall release the Performance Security to the Concessionaire.
9.4.2 Notwithstanding anything to the contrary contained in this Agreement, in the event Performance Guarantee is not provided by the Concessionaire within a period of [90] days prior to expiry of the Performance Security, the Authority may invoke and encash the Performance Security and appropriate the proceeds thereof as Damages, and thereupon all rights, privileges, claims and entitlements of the Concessionaire under or arising out of this Agreement shall be deemed to have been waived by, and to have ceased with the concurrence of the Concessionaire, and this Agreement shall be deemed to have been terminated by mutual agreement of the Parties.
Financial Guarantee 30.1 By derogation from article 30 of the General Conditions, no pre-financing guarantee is required.
Performance Guaranty Parent hereby guarantees the due, prompt and faithful performance and discharge by, and compliance with, all of the obligations, covenants, terms, conditions and undertakings of Merger Sub under this Agreement in accordance with the terms hereof, including any such obligations, covenants, terms, conditions and undertakings that are required to be performed, discharged or complied with following the Effective Time by the Surviving Corporation.
Parent Guarantee (a) Holdings hereby agrees to become a party to the Indenture as a Guarantor and in accordance with the amendments to the terms of the Indenture made in Section 2 of this Supplemental Indenture, to be substituted for STX as “Parent” under the Indenture, the Notes and the Parent Guarantee. Holdings shall have all of the rights and be subject to all of the obligations and agreements of Parent under the Indenture, the Notes and the Parent Guarantee. Holdings hereby unconditionally and irrevocably guarantees to each Holder and to the Trustee and its successors and assigns the Guaranteed Obligations in accordance with Article 10 of the Indenture.
(b) Holdings further agrees that the Guaranteed Obligations may be extended or renewed, in whole or in part, without notice or further assent from Holdings and that Holdings will remain bound by Article 10 of the Indenture notwithstanding any extension or renewal of any Guaranteed Obligation.
(c) Holdings waives presentation to, demand of, payment from and protest to Holdings of any of the Guaranteed Obligations and also waives notice of protest for nonpayment. Holdings waives notice of any default under the Notes or the Guaranteed Obligations. The obligations of Holdings under the Parent Guarantee shall not be affected by:
i. the failure of any Holder or the Trustee to assert any claim or demand or to enforce any right or remedy against Holdings or any other Person under this Indenture, the Notes or any other agreement or otherwise;
ii. any extension or renewal of any thereof;
iii. any rescission, waiver, amendment or modification of any of the terms or provisions of this Indenture, the Notes or any other agreement;
iv. the release of any security held by any Holder or the Trustee for the obligations of any of them;
v. the failure of any Holder or the Trustee to exercise any right or remedy against any other guarantor of the Guaranteed Obligations; or
vi. except as set forth in Section 10.05 of the Indenture, any change in the ownership of Holdings.
(d) Holdings further agrees that the Parent Guarantee constitutes a guarantee of payment, performance and compliance when due (and not a guarantee of collection) and waives any right to require that any resort be had by any Holder or the Trustee to any security held for payment of the Guaranteed Obligations.
(e) Except as expressly set forth in Sections 8.02 and 10.05 of the Indenture, the obligations of Holdings under the Parent Guarantee shall not be subject to any reduction, limitation, impairment or termination for any reason, including any claim of waiver, release, surrender, alteration or compromise, and shall not be subject to any defense of setoff, counterclaim, recoupment or termination whatsoever or by reason of the invalidity, illegality or unenforceability of the Guaranteed Obligations, this Indenture, the Notes or otherwise. Without limiting the generality of the foregoing, the obligations of Holdings under the Parent Guarantee shall not be discharged or impaired or otherwise affected by the failure of any Holder or the Trustee to assert any claim or demand or to enforce any remedy under this Indenture, the Notes or any other agreement, by any waiver or modification of any thereof, by any default, failure or delay, willful or otherwise, in the performance of the obligations, or by any other act or thing or omission or delay to do any other act or thing which may or might in any manner or to any extent vary the risk of Holdings or would otherwise operate as a discharge of Holdings as a matter of law or equity.
(f) Holdings further agrees that the Parent Guarantee shall continue to be effective or be reinstated, as the case may be, if at any time payment, or any part thereof, of principal of or premium (if any) on or interest on any Guaranteed Obligation is rescinded or must otherwise be restored by any Holder or the Trustee upon the bankruptcy or reorganization of the Company or otherwise.
(g) In furtherance of the foregoing and not in limitation of any other right which any Holder or the Trustee has at law or in equity against Holdings by virtue hereof, upon the failure of the Company to pay the principal of or premium (if any) on or interest on any Guaranteed Obligation when or to perform or comply with any other Guaranteed Obligation, Holdings hereby promises to and shall, upon receipt of written demand by the Trustee, forthwith pay, or cause to be paid, in cash, to the Holders or the Trustee an amount equal to the sum of (1) the unpaid amount of such Guaranteed Obligations, (2) accrued and unpaid interest on such Guaranteed Obligations (but only to the extent not prohibited by law) and (3) all other monetary Guaranteed Obligations of the Company to the Holders and the Trustee.
(h) Holdings further agrees that, as between it, on the one hand, and the Holders and the Trustee, on the other hand, (x) the maturity of the Guaranteed Obligations Guaranteed hereby may be accelerated as provided in Article 6 of the Indenture for the purposes of the Parent Guarantee, notwithstanding any stay, injunction or other prohibition preventing such acceleration in respect of the Guaranteed Obligations guaranteed hereby, and (y) in the event of any declaration of acceleration of such Guaranteed Obligations as provided in Article 6 of the Indenture, such Guaranteed Obligations (whether or not due and payable) shall forthwith become due and payable by Holdings for the purposes of Section 10.01 of the Indenture.
(i) Holdings also agrees to pay any and all costs and expenses (including reasonable attorneys’ fees and expenses) incurred by the Trustee or any Holder in enforcing any rights under Section 10.01 of the Indenture.
Performance Bank Guarantee 4.2.1 The Performance Bank Guarantee furnished by Power Producer to GUVNL shall be for guaranteeing the commissioining / commercial operation of the project up to the Contracted Capacity within SCOD.
4.2.2 If the Power Producer fails to commission the project on or before Scheduled Commercial Operation Date, GUVNL shall have the right to encash the Performance Bank Guarantee without prejudice to the other rights of the Power Producer under this Agreement as per Article 3.3.
4.2.3 GUVNL shall release the Performance Bank Guarantee upon successful commissioning of full contracted capacity after adjusting Liquidated Damages (if any) as per Article 3.3.
Performance Guarantees Contractor agrees to provide the County the performance guarantees specified in Attachment A and to pay any penalties incurred in accordance with the terms of Attachment A.
Guarantee The Guarantor irrevocably and unconditionally agrees to pay in full to the Holders the Guarantee Payments (without duplication of amounts theretofore paid by the Issuer), as and when due, regardless of any defense, right of set-off or counterclaim that the Issuer may have or assert. The Guarantor's obligation to make a Guarantee Payment may be satisfied by direct payment of the required amounts by the Guarantor to the Holders or by causing the Issuer to pay such amounts to the Holders.
Payment Guarantee 53.1. On Contracts where one hundred (100%) percent performance bonds and payment bonds are executed, this Article does not apply.
53.2. In the event the terms of this Contract do not require the Contractor to provide a payment bond or where the Contract does not require a payment bond for one hundred (100%) percent of the Contract price, the City shall, in accordance with the terms of this Article, guarantee payment of all lawful claims for:
53.2.1. Wages and compensation for labor performed and/or services rendered; and
53.2.2. Materials, equipment, and supplies provided, whether incorporated into the Work or not, when demands have been filed with the City as provided hereinafter by any person, firm, or corporation which furnished labor, material, equipment, supplies, or any combination thereof, in connection with the Work performed hereunder (hereinafter referred to as the “beneficiary”) at the direction of the City or the Contractor.
53.3. The provisions of Article 53.2 are subject to the following limitations and conditions:
53.3.1. If the Contractor provides a payment bond for a value that is less than one hundred (100%) percent of the value of the Contract Work, the payment bond provided by the Contractor shall be primary (and non-contributing) to the payment guarantee provided under this Article.
53.3.2. The guarantee is made for the benefit of all beneficiaries as defined in Article 53.2 provided that those beneficiaries strictly adhere to the terms and conditions of Articles 53.3.4 and 53.3.5.
53.3.3. Nothing in this Article shall prevent a beneficiary providing labor, services or material for the Work from suing the Contractor for any amounts due and owing the beneficiary by the Contractor.
53.3.4. Every person who has furnished labor or material, to the Contractor or to a Subcontractor of the Contractor, in the prosecution of the Work and who has not been paid in full therefor before the expiration of a period of ninety (90) Days after the date on which the last of the labor was performed or material was furnished by him/her for which the claim is made, shall have the right to sue on this payment guarantee in his/her own name for the amount, or the balance thereof, unpaid at the time of commencement of the action; provided, however, that a person having a direct contractual relationship with a Subcontractor of the Contractor but no contractual relationship express or implied with the Contractor shall not have a right of action upon the guarantee unless he/she shall have given written notice to the Contractor within one hundred twenty (120) Days from the date on which the last of the labor was performed or the last of the material was furnished, for which his/her claim is made, stating with substantial accuracy the amount claimed and the name of the party to whom the material was furnished or for whom the labor was performed. The notice shall be served by delivering the same personally to the Contractor or by mailing the same by registered mail, postage prepaid, in an envelope addressed to the Contractor at any place where it maintains an office or conducts its business; provided, however, that where such notice is actually received by the Contractor by other means, such notice shall be deemed sufficient.
53.3.5. Except as provided in Labor Law Section 220-g, no action on this payment guarantee shall be commenced after the expiration of the one-year limitations period set forth in Section 137(4)(b) of the State Finance Law.
53.3.6. The Contractor shall promptly forward to the City any notice or demand received pursuant to Article 53.
3.4. The Contractor shall inform the City of any defenses to the notice or demand and shall forward to the City any documents the City requests concerning the notice or demand.
Performance Security 47.1 Within twenty-one (21) days of the receipt of Letter of Acceptance from the Procuring Entity, the successful Tenderer, if required, shall furnish the Performance Security in accordance with the GCC 18, using for that purpose the Performance Security Form included in Section X, Contract Forms. If the Performance Security furnished by the successful Tenderer is in the form of a bond, it shall be issued by a bonding or insurance company that has been determined by the successful Tenderer to be acceptable to the Procuring Entity. A foreign institution providing a bond shall have a correspondent financial institution located in Kenya, unless the Procuring Entity has agreed in writing that a correspondent financial institution is not required.
47.2 Failure of the successful Tenderer to submit the above-mentioned Performance Security or sign the Contract shall constitute sufficient grounds for the annulment of the award and forfeiture of the Tender Security. In that event the Procuring Entity may award the Contract to the Tenderer offering the next lowest Evaluated Tender.
47.3 Performance security shall not be required for a contract, if so specified in the TDS.
Obligations of Covered Entity (1) Covered Entity shall notify Business Associate of any limitations in its notice of privacy practices of Covered Entity, in accordance with 45 C.F.R. § 164.520, or to the extent that such limitation may affect Business Associate’s use or disclosure of PHI.
(2) Covered Entity shall notify Business Associate of any changes in, or revocation of, permission by Individual(s) to use or disclose PHI, to the extent that such changes may affect Business Associate’s use or disclosure of PHI.
(3) Covered Entity shall notify Business Associate of any restriction to the use or disclosure of PHI that Covered Entity has agreed to in accordance with 45 C.F.R. § 164.522, to the extent that such restriction may affect Business Associate’s use or disclosure of PHI.
