SERVICE MONITORING, ANALYSES AND ORACLE SOFTWARE 11.1 We continuously monitor the Services to facilitate Oracle’s operation of the Services; to help resolve Your service requests; to detect and address threats to the functionality, security, integrity, and availability of the Services as well as any content, data, or applications in the Services; and to detect and address illegal acts or violations of the Acceptable Use Policy. Oracle monitoring tools do not collect or store any of Your Content residing in the Services, except as needed for such purposes. Oracle does not monitor, and does not address issues with, non-Oracle software provided by You or any of Your Users that is stored in, or run on or through, the Services. Information collected by Oracle monitoring tools (excluding Your Content) may also be used to assist in managing Oracle’s product and service portfolio, to help Oracle address deficiencies in its product and service offerings, and for license management purposes. 11.2 We may (i) compile statistical and other information related to the performance, operation and use of the Services, and (ii) use data from the Services in aggregated form for security and operations management, to create statistical analyses, and for research and development purposes (clauses i and ii are collectively referred to as “Service Analyses”). We may make Service Analyses publicly available; however, Service Analyses will not incorporate Your Content, Personal Data or Confidential Information in a form that could serve to identify You or any individual. We retain all intellectual property rights in Service Analyses. 11.3 We may provide You with the ability to obtain certain Oracle Software (as defined below) for use with the Services. If we provide Oracle Software to You and do not specify separate terms for such software, then such Oracle Software is provided as part of the Services and You have the non-exclusive, worldwide, limited right to use such Oracle Software, subject to the terms of this Agreement and Your order (except for separately licensed elements of the Oracle Software, which separately licensed elements are governed by the applicable separate terms), solely to facilitate Your use of the Services. You may allow Your Users to use the Oracle Software for this purpose, and You are responsible for their compliance with the license terms. Your right to use any Oracle Software will terminate upon the earlier of our notice (by web posting or otherwise) or the end of the Services associated with the Oracle Software. Notwithstanding the foregoing, if Oracle Software is licensed to You under separate terms, then Your use of such software is governed by the separate terms. Your right to use any part of the Oracle Software that is licensed under the separate terms is not restricted in any way by this Agreement.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.
Technology Research Analyst Job# 1810 General Characteristics
Apple and Android Devices The following terms apply when you use a mobile application obtained from either the Apple Store or Google Play (each an “App Distributor”) to access the Site:
RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
First Source Hiring Program Contractor must comply with all of the provisions of the First Source Hiring Program, Chapter 83 of the San Francisco Administrative Code, that apply to this Agreement, and Contractor is subject to the enforcement and penalty provisions in Chapter 83.
Mail Order Catalog Warnings In the event that, the Settling Entity prints new catalogs and sells units of the Products via mail order through such catalogs to California consumers or through its customers, the Settling Entity shall provide a warning for each unit of such Product both on the label in accordance with subsection 2.4 above, and in the catalog in a manner that clearly associates the warning with the specific Product being purchased. Any warning provided in a mail order catalog shall be in the same type size or larger than other consumer information conveyed for such Product within the catalog and shall be located on the same display page of the item. The catalog warning may use the Short-Form Warning content described in subsection 2.3(b) if the language provided on the Product label also uses the Short-Form Warning.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
How Do I Get More Information? This Notice summarizes the Action, the terms of the Settlements, and your rights and options in connection with the Settlements. More details are in the Settlement Agreements, which are available for your review at xxx.XxxxxxxxxXxxXxxxxxxxxXxxxxxxxxx.xxx. The Settlement Website also has the Second Amended Complaint and other documents relating to the Settlements. You may also call toll-free 0-000-000-0000 or write the Claims Administrator at: Financial Aid Antitrust Settlements, c/o Claims Administrator, 0000 Xxxx Xxxxxx, Xxxxx 0000, Xxxxxxxxxxxx, XX 00000. To: Settlement Class Member Email Address From: Claims Administrator Subject: Notice of Proposed Class Action Settlement – Xxxxx, et al. x. Xxxxx University, et al. Please visit xxx.XxxxxxxxxXxxXxxxxxxxxXxxxxxxxxx.xxx for more information. • The Court has preliminarily approved proposed settlements (“Settlements”) with the following ten schools: Brown University, the University of Chicago, the Trustees of Columbia University in the City of New York, Trustees of Dartmouth College, Duke University, Emory University, Northwestern University, Xxxxxxx Xxxxx Xxxx University, Vanderbilt University, and Yale University (collectively the “Settling Universities”). • The Court has also preliminarily approved a class of students who attended one or more of the Settling Universities during certain time periods. This is referred to as the “Settlement Class,” which is defined in more detail below.
Clinical Data and Regulatory Compliance The preclinical tests and clinical trials, and other studies (collectively, “studies”) that are described in, or the results of which are referred to in, the Registration Statement or the Prospectus were and, if still pending, are being conducted in all material respects in accordance with the protocols, procedures and controls designed and approved for such studies and with standard medical and scientific research procedures; each description of the results of such studies is accurate and complete in all material respects and fairly presents the data derived from such studies, and the Company and its subsidiaries have no knowledge of any other studies the results of which are inconsistent with, or otherwise call into question, the results described or referred to in the Registration Statement or the Prospectus; the Company and its subsidiaries have made all such filings and obtained all such approvals as may be required by the Food and Drug Administration of the U.S. Department of Health and Human Services or any committee thereof or from any other U.S. or foreign government or drug or medical device regulatory agency, or health care facility Institutional Review Board (collectively, the “Regulatory Agencies”); neither the Company nor any of its subsidiaries has received any notice of, or correspondence from, any Regulatory Agency requiring the termination, suspension or modification of any clinical trials that are described or referred to in the Registration Statement or the Prospectus; and the Company and its subsidiaries have each operated and currently are in compliance in all material respects with all applicable rules, regulations and policies of the Regulatory Agencies.
