Common use of POST AWARD MEETING Clause in Contracts

POST AWARD MEETING. A Post-Award Meeting shall be conducted within thirty (30) calendar days of contract award. During the Post Award Meeting, the Contractor shall provide a detailed briefing on its management and contract execution strategy. The contract briefing shall include: any updates following the proposal submittal; an organizational overview; key personnel; material purchasing and Production Readiness Review (PRR) schedules; a description of the Contractor’s quality process, including designation of the quality manager; and a discussion of risk and risk mitigation strategies. The Contractor shall plan for a one-day Post Award Meeting. The requirement for a Post Award Meeting shall, in no event, constitutes grounds for excusable delay by the Contractor in performance of the contract. After Government review of the initial invoice, the Procuring Contracting Officer (PCO), COR and Contractor may meet to review the adequacy of the supporting documentation that is submitted in accordance with C-242-H002 POST AWARD MEETING (NAVSEA) (OCT 2018).

POST AWARD MEETING. A Post-Award Meeting shall be conducted within thirty (30) calendar days of contract award. During the Post Award Meeting, the Contractor shall provide a detailed briefing on its management and contract execution strategy. The contract briefing shall include: any updates following the proposal submittal; an organizational overview; key personnel; material purchasing and Production Readiness Review (PRR) schedules; a description of the Contractor’s quality process, including designation of the quality manager; and a discussion of risk and risk mitigation strategies. The Contractor shall plan for a one-day Post Award Meeting. The requirement for a Post Award Meeting shall, in no event, constitutes grounds for excusable delay by the Contractor in performance of the contract. After Government review of the initial invoice, the Procuring Contracting Officer (PCO), COR Contracting Officer’s Representative (COR) and Contractor may meet to review the adequacy of the supporting documentation that is submitted in accordance with C-242-H002 POST AWARD MEETING (NAVSEA) (OCT 2018).