Goals and Objectives of the Agreement Agreement Goals The goals of this Agreement are to: ● Reduce wildfire risk related to the tree mortality crisis; ● Provide a financial model for funding and scaling proactive forestry management and wildfire remediation; ● Produce renewable bioenergy to spur uptake of tariffs in support of Senate Bill 1122 Bio Market Agreement Tariff (BioMat) for renewable bioenergy projects, and to meet California’s other statutory energy goals; ● Create clean energy jobs throughout the state; ● Reduce energy costs by generating cheap net-metered energy; ● Accelerate the deployment of distributed biomass gasification in California; and ● Mitigate climate change through the avoidance of conventional energy generation and the sequestration of fixed carbon from biomass waste. Ratepayer Benefits:2 This Agreement will result in the ratepayer benefits of greater electricity reliability, lower costs, and increased safety by creating a strong market demand for forestry biomass waste and generating cheap energy. This demand will increase safety by creating an economic driver to support forest thinning, thus reducing the risk of catastrophic wildfire and the associated damage to investor-owned utility (IOU) infrastructure, such as transmission lines and remote substations. Preventing this damage to or destruction of ratepayer-supported infrastructure lowers costs for ratepayers. Additionally, the ability of IOUs to use a higher- capacity Powertainer provides a much larger offset against the yearly billion-dollar vegetation management costs borne by IOUs (and hence by ratepayers). The PT+’s significant increase in waste processing capacity also significantly speeds up and improves the economics of wildfire risk reduction, magnifying the benefits listed above. The PT+ will directly increase PG&E’s grid reliability by reducing peak loading by up to 250 kilowatt (kW), and has the potential to increase grid reliability significantly when deployed at scale. The technology will provide on-demand, non- weather dependent, renewable energy. The uniquely flexible nature of this energy will offer grid managers new tools to enhance grid stability and reliability. The technology can be used to provide local capacity in hard-to-serve areas, while reducing peak demand. Technological Advancement and Breakthroughs:3 This Agreement will lead to technological advancement and breakthroughs to overcome barriers to the achievement of California’s statutory energy goals by substantially reducing the LCOE of distributed gasification, helping drive uptake of the undersubscribed BioMAT program and increasing the potential for mass commercial deployment of distributed biomass gasification technology, particularly through net energy metering. This breakthrough will help California achieve its goal of developing bioenergy markets (Bioenergy Action Plan 2012) and fulfil its ambitious renewable portfolio standard (SB X1-2, 2011-2012; SB350, 2015). The PT+ will also help overcome barriers to achieving California’s greenhouse gas (GHG) emissions reduction (AB 32, 2006) and air quality improvement goals. It reduces greenhouse gas and criteria pollutants over three primary pathways: 1) The PT+’s increased capacity and Combined Heat and Power (CHP) module expand the displacement of emissions from conventional generation; 2) the biochar offtake enables the sequestration of hundreds of tons carbon that would otherwise have been released into the atmosphere; and 3) its increased processing capacity avoids GHG and criteria emissions by reducing the risk of GHG emissions from wildfire and other forms of disposal, such as open pile burning or decomposition. The carbon sequestration potential of the biochar offtake is particularly groundbreaking because very few technologies exist that can essentially sequester atmospheric carbon, which is what the PT+ enables when paired with the natural forest ecosystem––an innovative and groundbreaking bio-energy technology, with carbon capture and storage. Additionally, as noted in the Governor’s Clean Energy Jobs Plan (2011), clean energy jobs are a critical component of 2 California Public Resources Code, Section 25711.5(a) requires projects funded by the Electric Program Investment Charge (EPIC) to result in ratepayer benefits. The California Public Utilities Commission, which established the EPIC in 2011, defines ratepayer benefits as greater reliability, lower costs, and increased safety (See CPUC “Phase 2” Decision 00-00-000 at page 19, May 24, 2012, xxxx://xxxx.xxxx.xx.xxx/PublishedDocs/WORD_PDF/FINAL_DECISION/167664.PDF). 3 California Public Resources Code, Section 25711.5(a) also requires EPIC-funded projects to lead to technological advancement and breakthroughs to overcome barriers that prevent the achievement of the state’s statutory and energy goals. California’s energy goals. When deployed at scale, the PT+ will result in the creation of thousands of jobs across multiple sectors, including manufacturing, feedstock supply chain (harvesting, processing, and transportation), equipment operation, construction, and project development. ● Annual electricity and thermal savings; ● Expansion of forestry waste markets; ● Expansion/development of an agricultural biochar market; ● Peak load reduction; ● Flexible generation; ● Energy cost reductions; ● Reduced wildfire risk; ● Local air quality benefits; ● Water use reductions (through energy savings); and ● Watershed benefits.
Project Specific Milestones In addition to the milestones stated in Section 212.5 of the Tariff, as applicable, during the term of this ISA, Interconnection Customer shall ensure that it meets each of the following development milestones: 6.1 Substantial Site work completed. On or before December 31, 2020 Interconnection Customer must demonstrate completion of at least 20% of project site construction. At this time, Interconnection Customer must submit to Interconnected Transmission Owner and Transmission Provider initial drawings, certified by a professional engineer, of the Customer Interconnection Facilities. 6.2 Delivery of major electrical equipment. On or before December 31, 2021, Interconnection Customer must demonstrate that all generating units have been delivered to Interconnection Customer’s project site.
ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Project/Milestones Taxpayer provides refrigerated warehousing and logistic distribution services to clients throughout the United States. In consideration for the Credit, Taxpayer agrees to invest in a new refrigeration and distribution facility in the XxXxxxxxx Park area of Sacramento, California, and hire full-time employees (collectively, the “Project”). Further, Taxpayer agrees to satisfy the milestones as described in Exhibit A (“Milestones”) and must maintain Milestones for a minimum of three (3) taxable years thereafter. In the event Taxpayer employs more than the number of full-time employees, determined on an annual full-time equivalent basis, than required in Exhibit A, for purposes of satisfying the “Minimum Annual Salary of California Full-time Employees Hired” and the “Cumulative Average Annual Salary of California Full-time Employees Hired,” Taxpayer may use the salaries of any of the full-time employees hired within the required time period. For purposes of calculating the “Minimum Annual Salary of California Full-time Employees Hired” and the “Cumulative Average Annual Salary of California Full-time Employees Hired,” the salary of any full-time employee that is not employed by Taxpayer for the entire taxable year shall be annualized. In addition, the salary of any full-time employee hired to fill a vacated position in which a full-time employee was employed during Taxpayer’s Base Year shall be disregarded.
Effective Date Deliveries On the Effective Date, the Company shall have delivered to the Representative executed copies of the Trust Agreement, the Warrant Agreement, the Registration Rights Agreement, all of the Insider Letters and the Subscription Agreement.
Modifications and Updates to the Wire Center List and Subsequent Transition Periods 5.4.6.1 In the event AT&T identifies additional wire centers that meet the criteria set forth in Sections 5.4.2.1 or 5.4.2.2 above, but that were not included in the Master List of Unimpaired Wire Centers or AT&T’s List of Unimpaired Wire Centers, AT&T shall include such additional wire centers in a CNL. Each such list of additional wire centers shall be considered a Subsequent Wire Center List. AT&T will follow any limitations on the frequency with which it may issue such lists and notification procedures set forth in applicable Commission orders. 5.4.6.2 TWTC shall have thirty (30) business days to dispute the additional wire centers listed on AT&T’s CNL. Absent such dispute, effective thirty (30) business days after the date of a AT&T CNL providing a Subsequent Wire Center List, AT&T shall not be required to provide DS1 and DS3 Dedicated Transport, as applicable, in such additional wire center(s), except pursuant to the self-certification process as set forth in Section 1.9.1 of this Attachment. 5.4.6.3 For purposes of Section 5.4.6.1 above, AT&T shall make available DS1 and DS3 Dedicated Transport that were in service for TWTC in a wire center on the Subsequent Wire Center List as of the thirtieth (30th) business day after the date of AT&T’s CNL identifying the Subsequent Wire Center List (Subsequent Embedded Base) until one hundred eighty (180) days after the thirtieth (30th) business day Version: 4Q06 Standard ICA 11/30/06 from the date of AT&T’s CNL identifying the Subsequent Wire Center List (Subsequent Transition Period). 5.4.6.4 The rates set forth in Exhibit B shall apply to the Subsequent Embedded Base during the Subsequent Transition Period. 5.4.6.5 No later than one hundred eighty (180) days from AT&T’s CNL identifying the Subsequent Wire Center List, TWTC shall submit an LSR(s) or spreadsheet(s) as applicable, identifying the Subsequent Embedded Base of circuits to be disconnected or converted to other AT&T services. 5.4.6.5.1 In the case of disconnection, the applicable disconnect charges set forth in this Agreement shall apply. 5.4.6.5.2 If TWTC chooses to convert DS1 and/or DS3 Dedicated Transport to special access circuits in existence as of the Effective Date of this Agreement, AT&T will include such DS1 and/or DS3 Dedicated Transport within TWTC’s total special access circuits, and apply any discounts to which TWTC is entitled from the transition period of 3/11/2006 to the conversion date. Conversions will be subject to the switch-as-is charge set forth in Exhibit A to this Attachment 2. 5.4.6.5.3 AT&T shall not impose disconnect or nonrecurring installation charges when transitioning the Subsequent Embedded Base of DS1 and DS3 Dedicated Transport in existence as of the Effective Date of this Agreement. 5.4.6.6 If TWTC fails to submit the LSR(s) or spreadsheet(s) for all of its Subsequent Embedded Base by one hundred eighty (180) days after the date of AT&T’s CNL identifying the Subsequent Wire Center List, AT&T will identify TWTC’s remaining Subsequent Embedded Base, if any, and will transition such circuits to the equivalent tariffed AT&T service(s), or in the case of Georgia, to the equivalent 271 service(s) set forth in Exhibit 1. In the states of Florida, Kentucky, Mississippi and South Carolina, those circuits identified and transitioned by AT&T shall be subject to the applicable disconnect charges as set forth in this Agreement and the full nonrecurring charges for installation of the equivalent tariffed AT&T service as set forth in AT&T’s tariffs. In the states of Alabama, Georgia, North Carolina and Tennessee, those circuits identified and transitioned by AT&T shall be subject to the applicable switch-as-is rates set forth in Exhibit A of Attachment
Post-Commercial Operation Date Testing and Modifications Each Party shall at its own expense perform routine inspection and testing of its facilities and equipment in accordance with Good Utility Practice as may be necessary to ensure the continued interconnection of the Large Generating Facility with the Participating TO’s Transmission System in a safe and reliable manner. Each Party shall have the right, upon advance written notice, to require reasonable additional testing of the other Party’s facilities, at the requesting Party’s expense, as may be in accordance with Good Utility Practice.
Commercial Operation Date Testing and Modifications Prior to the Commercial Operation Date, the Connecting Transmission Owner shall test the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades and Developer shall test the Large Generating Facility and the Developer Attachment Facilities to ensure their safe and reliable operation. Similar testing may be required after initial operation. Developer and Connecting Transmission Owner shall each make any modifications to its facilities that are found to be necessary as a result of such testing. Developer shall bear the cost of all such testing and modifications. Developer shall generate test energy at the Large Generating Facility only if it has arranged for the injection of such test energy in accordance with NYISO procedures.
– OTHER SPECIAL CONDITIONS I. 12.1 Exchange rate applicable for the conversion of currencies into euro Payments shall be made by the Commission in euro. The co-ordinator shall submit the payment requests in accordance with article I.5.3, including the underlying financial statements, in euro. By way of derogation from article II.16.1, any conversion of actual costs into euro shall be made by the beneficiary at the monthly accounting rate established by the Commission and published on its website applicable on the day when the cost was incurred.
Final Completion Date Final Completion for the Work as defined in Article 6.1.3 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by October 31, 2024.