Contractor’s Remedies If the State is in breach of any provision of this Participating Addendum and does not cure such breach, Contractor, following the notice and cure period in §13 and the dispute resolution process in §15 shall have all remedies available at law and equity. If a Purchasing Entity is in breach of a provision of an Order, Contractor shall have all remedies available to it under that Order and available at law and equity.
For the Contractor Name: Xxxxx Xxxx Phone: 000-000-0000 Email: xxxxx@xxxxxxxxxxxxxxx.xxx
Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.
The Contractor A general contractor shall be retained by Tenant to construct the Improvements. Such general contractor (“Contractor”) shall be selected by Tenant from a list of general contractors supplied by Landlord, and Tenant shall deliver to Landlord notice of its selection of the Contractor upon such selection.
Responsibilities of the Contractor The Contractor shall provide all technical and professional expertise, knowledge, management, and other resources required for accomplishing all aspects of the tasks and associated activities identified in the Scope of Work. In the event that the need arises for the Contractor to perform services beyond those stated in the Scope of Work, the Contractor and the City shall negotiate mutually agreeable terms and compensation for completing the additional services.
CONTRACT REMEDIES To ensure Xxxxxxx’s full performance of the Contract and compliance with applicable law, the System Agency reserves the right to hold Grantee accountable for breach of contract or substandard performance and may take remedial or corrective actions, including, but not limited to: i. suspending all or part of the Contract; ii. requiring the Grantee to take specific actions in order to remain in compliance with the Contract; iii. recouping payments made by the System Agency to the Grantee found to be in error; iv. suspending, limiting, or placing conditions on the Grantee’s continued performance of the Project;
CONTRACTOR BREACH, ERRORS AND OMISSIONS Any breach of the terms of this contract, or material errors and omissions in the work product of the contractor must be corrected by the contractor at no cost to the State, and a contractor may be liable for the State's costs and other damages resulting from errors or deficiencies in its performance.
PARTIES TO THE CONTRACT This Contract is solely between the Company and the SBA which administers the FHCF. In no instance shall any insured of the Company or any claimant against an insured of the Company, or any other third party, have any rights under this Contract, except as provided in Article XIV. The SBA will only disburse funds to the Company, except as provided for in Article XIV of this Contract. The Company shall not, without the prior approval of the Office of Insurance Regulation, sell, assign, or transfer to any third party, in return for a fee or other consideration any sums the FHCF pays under this Contract or the right to receive such sums.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS. B. Such liquidated damages shall be calculated as an amount equaling the difference between: 1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and 2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract. C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Remedies for Contractor Breach Pertaining to contract-related issues, it is the responsibility of both CMHA and the contractor to communicate with each other in as clear and complete a manner as possible. If at any time during the term of this contract CMHA or the contractor is not satisfied with any issue, it is the responsibility of that party to deliver to the other party communication, in writing, fully detailing the issue and corrective action (please note that CMHA has the right to issue unilateral addendums to this contract, but the contractor does not have the same right). The other party shall, within 10 days, respond in writing to the other party (however, CMHA shall retain the right to, if conditions warrant, require the contractor to respond in a shorter period of time). Further, CMHA shall, at a minimum, employ the following steps in dealing with the contractor as to any performance issues: 20.16.1.1. If the contractor is in material breach of the contract, CMHA may promptly invoke the termination clause detailed within Section No. 3, form HUD-5370-C, General Conditions for Non-Construction Contracts, Section I—(With or without Maintenance Work), which is attached hereto, and terminate the contract for cause. Such termination must be delivered to the contractor in writing and shall fully detail all pertinent issues pertaining to the cause of and justification for the termination. 20.16.1.2. Prior to termination, CMHA may choose to warn 20.16.1.3. After termination, if the contractor does not agree with CMHA’s justification for the termination, the contractor shall have 10 days to dispute, in writing, such action; if he/she does not do so within the 10-day period, he/she shall have no recourse but to accept and agree with CMHA’s position on the issue. The written protest must detail all pertinent information pertaining to the dispute, including justification detailing CMHA’s alleged incorrect action(s). 20.16.1.4. The response to any protest received shall be conducted in accordance with Section No. 4.0 of this document. 20.16.1.5. It is CMHA’s policy to resolve all contractual issues informally and without litigation. Disputes will not be referred to HUD unless all administrative remedies have been exhausted. When appropriate, a mediator may be used to help resolve differences. 20.16.1.6. For contracts of $100,000 or less, the bidder/contractor may request to meet with the Procurement Officer. 20.16.1.7. All claims by a contractor relating to performance of a contract shall be submitted in writing to the Procurement Officer or designee for a written decision. The contractor may request a conference on the claim. The Procurement Officer’s decision shall inform the contractor of its appeal rights to the next higher level of authority in CMHA. Contractor claims shall be governed by the Changes clause in the form HUD-5370-C.
